HomeMy WebLinkAbout01 Request for Qualifications_Template - Rexburg Fall 20241 RFQ: CM/GC Services – (Police Station Facility Project)
CITY of Rexburg
REQUEST FOR QUALIFICATIONS
CONSTRUCTION MANAGER / GENERAL CONTRACTOR CM/GC SERVICES:
(Police Station Facility Project)
1 RFQ: CM/GC Services – (Police Station Facility Project)
REQUEST FOR QUALIFICATIONS (RFQ): CM/GC
SERVICES
[11/07/2024]
CITY of Rexburg (CITY) will accept Statements of Qualifications (SOQs) from licensed Idaho Public Works
Construction Managers in good standing to perform construction manager services in accordance with
Idaho Code § 54-4501 et seq., and as determined by CITY for a new police station facility..
CITY has plans to use the Construction Manager / General Contractor (CM/GC) delivery process. In
accordance with the Qualification Based Selection process set forth in Idaho Code § 67-2320, CITY is
seeking SOQs from qualified firms to provide CM/GC services to assist with this project.
Written SOQs will be received at the offices of CITY, 35 North 1st East Rexburg, ID 83440 until 3 pm on
December 2nd3rd, 2024. Each SOQ will be evaluated on the basis of qualifications as specified in this
RFQ. A selection committee will evaluate each of the SOQs and the committee may choose to
conduct interviews with one or more of the firms. The CITY will make the final decision regarding the
firm chosen for CM/GC services for this project.
CITY reserves the right to reject any and all SOQs, to waive any irregularities in the SOQs received, and
to select the CM/GC that is in the best interest of CITY and the public. The issuance of the RFQ and
the receipt and evaluation of sealed SOQs does not obligate CITY to award a contract. CITY will pay
no costs incurred in responding to this RFQ. CITY may in its discretion cancel this process at any time
prior to execution of a contract without liability.
A Pre-Proposal Meeting will be held at 35 N 1st E Rexburg Idaho (City Hall) at 2 PM on November 21,
2024. CITY strongly recommends attendance by all Respondents, or in other words, those firms
responding to this RFQ.
CITY appreciates the opportunity to review the SQQs and look forward to selecting and working with a
qualified firm to help determine the possibilities for a Police Station Facility Project.
Formatted: Body Text, Justified, Right: 0.25", Space
Before: 0 pt
2 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 1
INSTRUCTIONS TO RESPONDENTS
1.1 SOQ Information
Statements of Qualification shall be submitted in an opaque envelope or box and must be sealed and
plainly marked for delivery as follows:
Please indicate “CM/GC: [Police Station Facility Project] - SEALED STATEMENT OF QUALIFICATION
ENCLOSED” on the outside of the submittal package. Also indicate on the outside of the submittal
package, the firm name of the Respondent.
SOQs shall be delivered to:
City of Rexburg
Attention: City Clerk
35 N 1st E
Rexburg, ID 83440
Please sign your SOQ. SOQ must not be more than fifteen (15) pages including the exhibits. UNSIGNED
SOQs MAY NOT BE ACCEPTED. Submittal packages must include:
a. ONE (1) signed/printed original SOQ.
b. At least eight (8) printed copies of the SOQ.
c. ONE (1) digital (PDF) version of the entire SOQ on a Flash Drive.
Late or incomplete submissions will not be accepted. Email or fax submissions will not be accepted.
SOQ deadline is 3 pm local time, 12/3/2024
At the time of the deadline above, only the names of the Respondents will be made public. Respondent
assumes full responsibility for the timely delivery of its submittal package to CITY. Respondent will be
responsible for all costs (including site visits if needed) incurred in preparing or responding to this RFQ.
All materials and documents submitted in response to this RFQ become the property of CITY and will not
be returned.
1.2 Contact with CITY Personnel
All communications by Respondent should be made via the below-named contact.
Address all communications concerning this RFQ in writing to:
Brandy Davis
City of Rexburg
35 N 1st E
Rexburg, ID 83440
Email: brandy.davis@rexburg.org
1.3 CM/GC Selection Process Anticipated Schedule
RFQ Advertisements: November 12th and 19th, 2024
RFQ Available: November 7th, 2024
Pre-Proposal Meeting: November 21st, 2024
3 RFQ: CM/GC Services – (Police Station Facility Project)
SOQ Deadline: December 3rd, 2024
Evaluation Committee Rankings: December 19th, 2024
Interview Notification (if required for selection): December 20th, 2025
Interviews (if required) and Selection: January 6-10th, 2025
Recommendation to [CITY Council]: January 15th22nd, 2025
1.4 Rates, Overhead, Multipliers, and other Cost Information
While CM rates, overhead, and multipliers may be requested for reference during the selection process,
pursuant to Idaho Code § 67-2320, Respondents shall not provide any cost information, related to this
project, in their SOQ.
4 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 2
PROJECT INFORMATION
2.1 Project Location
TBD Rexburg Idaho
Acreage needed TBD as well.
2.2 Project Budget
TBD $10 to $17 million for a new facility
2.3 Project Description, Information, and Background
Rexburg Idaho is desiring to build a New Police Station Facility Project in the City of Rexburg. To build a
new facility, it will likely be necessary to secure a general obligation bond, which would have to be
approved in the future by the residents of Rexburg. Rexburg is desiring to work with the CM/GC to help
develop some final preliminary cost estimates and designs of a potential New Police Station Facility to
present to our City Council and potentially to our citizens as a potential ballot request that would also
provide tax affects related to property owners if they were to choose to pass a general obligation bond
to fund either project. The city has been and will continue to save money in reserve to help reduce the
needed potential obligation amount to our citizens for the chosen facility.
2.4 Project Timeline
The design is currently at a beginning level. Pre-construction services for the project will begin as soon as
possible, after the project award and contract negotiations are complete. It is anticipated that the
potential construction of a new Police Station Facility Project could begin as soon as Summer of 2026.
2.5 CM/GC Scope of Services
All CM/GC contracted services must be performed by staff properly licensed in the State of Idaho. The
following services are anticipated in the CM/GC Services agreement with CITY. The descriptions are
illustrative in nature and not exhaustive. The actual scope of services will be negotiated after this RFQ
selection process has been conducted.
Preconstruction Phase for Design and Construction Estimates to be able to possibly take to the public
for a vote on a General Obligation (GO) Bond:
• CM/GC would be responsible to hire or subcontract a qualified Architect to be part of their team
for determined design requirements and provide a preliminary design of the facility with the
CITY;
• Work with CITY staff and the design team to review the project and visit the work areas to
become familiar with the project; Property has not been selected yet for the option of a new
Police Station Facility, but we hope to identify the property option(s) as part of this process;
• Review draft design drawings and specifications to identify clarity and constructability
issues;
• Provide cost estimates as needed and required in the contract;
• Work with staff to develop a project schedule(s) and refine the logistics plans;
• As necessary, provide recommendations regarding accelerated or fast track scheduling,
procurement, or phased construction;
If the residents pass a GO bond:
5 RFQ: CM/GC Services – (Police Station Facility Project)
• Develop and disseminate trade contract scopes and other contract documents;
• Establish bidder interest and obtain competitive bids for all the work, materials, and
equipment;
• Work with CITY staff and the design team to address questions, issue addendums, and
publicly open bids;
• Work with CITY staff and design team to value engineer the design and reconcile budget
overruns as needed;
• Research and coordinate with specialty contractors and vendors on specialized items;
• Work with CITY staff to derive and negotiate project Guaranteed Maximum Price (GMP).
If the project will require multiple bid packages/GMPs the following statement will apply to the pre-
construction services provided by the CM/GC. Prior to release of the first package for the
subcontractor bidding, CM/GC firm shall submit a bid package estimate that itemizes all bid packages
to be bid and awarded and which includes the CM/GC firm’s estimate of the cost of each bid package.
As permitted by the Owner, the bid package estimate will include line items for any work the CM/GC
firm proposes to self-perform. CM/GC firm’s overhead, profit, and contingencies shall be identified in
separate line items. The total of the bid package estimate shall equal the Construction Cost on the
CM/GC firm’s most recent estimate.
The next phase of the project will only begin if the residents pass a GO bond, or the city determines
alternative funding that allows them to move forward to the construction and following phases.
Construction Phase Service:
• Obtain project bonding, issue subcontracts and trade contracts, and obtain permits for all the
work;
• Serve as the General Contractor and as a licensed Construction Manager, including:
o Work with a qualified Architect and city and complete the final design of the construction
project
o Manage the construction process including the coordination, planning, trade contractor
management, submittals management, procurement of long-lead material items, and
requests for information;
o Plan and provide general condition services such as site management, mobilization,
storage areas, staging, et cetera
o Obtain permission and coordinate access with public and private property
owners implicated by the construction activity.
o Review and negotiate change orders, and resolve issues and claims;
o Coordinate safety programs, and maintain a safe job site;
o Ensure project quality and conduct and coordinate inspections;
o Update construction schedules as required to meet project milestones;
o Conduct and document coordination meetings;
o Maintain records, record documents, and manuals;
o Develop, monitor, and complete project punch list;
o Coordinate and assist with warranty corrections.
2.6 Special Instructions
Throughout the project, the CM/GC firm shall provide CITY with professional construction management
and contractor services and represent CITY’s interests in completing the project on time, within set
budgets, and as planned with minimum difficulties. It is anticipated that standard AIA or Consensus Docs
contracts will form the basis of agreement for CM/GC services to be entered into for the project;
6 RFQ: CM/GC Services – (Police Station Facility Project)
provided however, CITY reserves the right to change, modify, or amend the final contract to be entered
into by CITY.
7 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 3
GENERAL CONDITIONS OF RFQ
3.1 Intent of RFQ
It is the intent of CITY to run a Qualification Based Selection process to select a firm capable of providing
the CM/GC services, including but not limited to, those outlined within this RFQ. The Respondent ranked
highest will be approached to negotiate the contract(s) necessary for this project. If contracts cannot be
negotiated, CITY will then approach the next highest ranked Respondent to negotiate the contracts
pursuant to Idaho Code § 67-2320.
3.2 Reserved Rights
CITY reserves the right to act in the public best interest and in furtherance of the purposes of Idaho
Code Title 67, Chapter 28 (Purchasing by Political Subdivisions). CITY reserves the right to waive any
formalities or defects as to form, procedure, or content with respect to its Request for Qualifications
and any irregularities in the SOQs received, to request additional data and information from any and all
Respondents, to reject any submissions based on real or apparent conflict of interest, to reject any
submissions containing inaccurate or misleading information, and to accept the SOQ that is in the best
interest of CITY and the public. The issuance of this RFQ and the receipt and evaluation of SOQs does
not obligate CITY to select a firm nor award a contract. CITY may in its discretion cancel, postpone, or
amend this RFQ at any time without liability.
3.3 Public Records
CITY is a public entity. All documents in its possession are public records subject to inspection and
copying under the Idaho Public Records Law, Idaho Code §§ 74-101 through 74-125. The Public Records
Law contains certain exemptions – one of which that is potentially applicable to part of your response is
an exemption for trade secrets. Trade secrets may include a formula, pattern, compilation, program,
computer program, device, method, technique or process that derives economic value, actual or
potential, from not being generally known to, and not being readily ascertainable by proper means by
other persons and is subject to the efforts that are reasonable under the circumstances to maintain its
secrecy. Prices quoted in a SOQ are not trade secrets.
If any Respondent claims any part of a SOQ is exempt from disclosure under the Idaho Public Records
Law, the Respondent must: 1.) Indicate by marking the pertinent document “CONFIDENTIAL”; and, 2.)
Include the specific basis for the position that it be treated as exempt from disclosure. Marking the entire
SOQ as “CONFIDENTIAL” is not in accordance with Idaho Public Records Law and will not be honored.
CITY, to the extent allowed by law and in accordance with these Instructions, will honor a nondisclosure
designation. By claiming material to be exempt from disclosure under the Idaho Public Records Law,
Respondent expressly agrees to defend, indemnify, and hold CITY harmless from any claim or suit arising
from CITY’s refusal to disclose such materials pursuant to the Respondent’s designation. Any questions
regarding the applicability of the Public Records Law should be addressed to your own legal counsel prior
to submission.
3.4 Insurance
Prior to executing any contract for CM/GC services with CITY or commencing any work under the
contract, the CM/GC firm will be required to provide evidence of the coverages listed below and pay all
costs associated with the insurance coverage. Insurance policies or certificates of insurance will name
CITY as a named insured, (except professional liability and worker’s compensation insurance) and the
8 RFQ: CM/GC Services – (Police Station Facility Project)
CM/GC firm will maintain these minimum insurance coverages during the entire term of the contract:
a. Professional Liability Insurance coverage with minimum coverage of One Million Dollars
($1,000,000.00) per occurrence and a minimum aggregate limit of One Million Dollars
($1,000,000.00).
b. Commercial General Liability Insurance coverage with minimum coverage of Two Million
Dollars ($2,000,000.00) on an occurrence basis (rather than a claims- made basis).
c. Automobile Insurance coverage with minimum coverage of One Million Dollars
($1,000,000.00) per occurrence for owned, non-owned, and hired vehicles.
d. Worker’s Compensation Insurance in an amount as required by statute and Employer’s
Liability Insurance in an amount not less than One Million Dollars ($1,000,000.00) for each
occurrence, for all of the firm’s employees to be engaged in work on the project under
contract and, in the case any such work is subcontracted, the CM/GC firm will require
Subcontractors and trade contractors similarly to provide Worker’s Compensation and
Employer’s Liability Insurance for all the Subcontractors and trade contractors to be
engaged in such work.
3.5 Bonding
As the General Contractor, the CM/GC must have the capability to bond 100% of the contract price of
the project estimated at the time the contract is negotiated and until such time that all of the entire
projects bid, the overall Guaranteed Maximum Price (GMP) for the work is established, and the bond is
delivered to CITY. The performance and payment bonds shall be AIA Document A312, 2010, or a
standard surety form certified approved to be the same as the AIA A312 form and shall be executed by a
surety or sureties reasonably acceptable to CITY and authorized to do business in the State of Idaho.
3.6 Taxes
CITY is exempt from Federal and State taxes and will execute the required exemption certificates for
items purchased and used by CITY. Items purchased by CITY and used by a contractor may be subject to
Use Tax. All other taxes are the responsibility of the Contractor and are to be included in the
Contractor’s pricing.
3.7 Legal Residency Requirement
By submitting a SOQ, the Respondent attests, under penalty of perjury, that they are a United States
citizen or legal permanent resident or that they are otherwise lawfully present in the United States
pursuant to federal law. Prior to being issued a contract, the firm will be required to submit proof of
lawful presence in the United States in accordance with Idaho Code § 67- 7903.
3.8 License Requirements
Proposals will be accepted from Idaho licensed construction managers and the firm of which they are a
principal or full-time employee who, prior to the SOQ deadline, also have a valid public works
contractor license as a general contractor pursuant to Idaho Code § 54-1902.
Idaho Code § 54-1902 requires that public works contractors and subcontractors have the appropriate
Public Works License for the particular type of construction work involved, and the general contractor
must perform at least 20% of the work under contract.
9 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 4
SUBMISSION PROCESS
4.1 Pre-Proposal Meeting
A Pre-Proposal Meeting will be held at the 35 N 1st E Rexburg Idaho at 2 PM on November 21, 2024. CITY
strongly recommends attendance by all Respondents.
4.2 Forms Submitted
Respondents must submit the following items by the SOQ deadline:
a. ONE (1) signed/printed original SOQ that is not more than fifteen (15) pages including exhibits.
b. At least eight (8) printed copies of the SOQ.
c. ONE (1) digital (PDF) version of the entire SOQ on a Flash Drive.
d. Exhibit A and B Forms (Included in the SOQ as described in SECTION 5 of this RFQ).
o RFQ Submittal Information Form – Attached to this RFQ as Exhibit A
o RFQ Waiver and Release Form – Attached to this RFQ as Exhibit B
Failure to submit all requested information may render any SOQ nonresponsive and void.
4.3 Objections to Specifications or Process
Objections to specifications or RFQ procedures must be in writing and received by CITY, Attn: Brandy Davis
at least three (5) business days before the SOQ due date and time. The objection must state the exact
nature of the protest, describing the location of the protest portion or clause in the RFQ and explaining
why the provision should be struck, added, or altered, and contain suggested corrections. CITY may deny
the objection, modify this RFQ, and/or reject all or part of the objection.
4.4 Addenda
In the event it becomes necessary to revise any part of this RFQ, addenda will be issued. Information
given to one Respondent will be available to all other Respondents if such information is necessary for
purposes of submitting a SOQ or if failure to give such information would be prejudicial to uninformed
Respondents. It is the Respondents’ responsibility to check for addenda prior to submitting a SOQ.
Failure to do so may result in the SOQ being declared nonresponsive. No addenda will be issued less
than three (3) business days before the SOQ deadline unless the deadline is extended.
4.5 Modification or Withdrawal of SOQ
A SOQ may be modified or withdrawn by the Respondent prior to the submission deadline set forth in
this RFQ. After the submission deadline, the submitted SOQ shall remain in effect for a minimum of 90
days for evaluation purposes.
4.6 Protest
If any participating Respondent objects to CITY’s notice of selecting a firm for CM/GC services, that
Respondent shall respond in writing to the notice from CITY within seven (7) calendar days of the date of
transmittal of the notice, stating the express reason or reasons that the decision of CITY’s governing body
is in error. Upon receipt of such objection, the CITY’s governing body shall review the award and
determine whether to affirm, modify or re-issue the RFQ, setting forth the reason or reasons for its
decision. At completion of the review process, CITY may proceed as it deems to be in the best interest of
CITY and the public.
10 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 5
REQUIRED CONTENT, EVALUATION, AND SELECTION
5.1 Required Submission Materials and Format
The SOQ format described here is meant to allow uniform review and easy access to information by the
evaluation committee. Respondents not conforming to the requested format or not in compliance with
the specifications may be considered nonresponsive.
SOQs must include the following information in the sequence set forth below. Respondents
acknowledge they will be ranked according to articles below, with points applied per article:
Pass/Fail Proposal Criteria – organized with the following information:
Cover Letter: A signed letter briefly stating the Respondent’s understanding of the work to be
done, the commitment to perform the work within the time period, and a statement as to why
the firm believes it is qualified to perform CM/GC services for the project. Behind the Cover
Letter, please submit a completed RFQ Submittal Information Form (Exhibit A) and a completed
RFQ Waiver and Release Form (Exhibit B).
Scored Proposal Criteria– organized with the following information:
SECTION 1 | Company Profile: Describe the firm’s history, size, resources, philosophy of service,
typical volume of work, financial stability, and basic construction management techniques and
methods. Describe how your particular expertise, experience, and techniques can be an
advantage to CITY in completing the projects. 30 Points
SECTION 2 | CM/GC Approach: Describe the firm’s philosophy and approach to providing
CM/GC services during both the Pre-construction and Construction phases of the project. Also
include a description of your post construction approach including your firm's warranty
program. 20 Points
SECTION 3 | Key Project Personnel: Identify the personnel to whom CM/GC responsibilities will
be assigned. Also include the key personnel from the Architect firm. Include names, titles, roles,
qualifications, years of experience, project experience, and resumes. Please identify your firm's
main point of contact for this project. Also, provide an organization chart clearly illustrating key
and support personnel for your project team. 30 Points
SECTION 4 | Budget Control: Submit detailed information of how your firm provides budget
control throughout all phases of the project. This shall include but is not limited to, periodic
updates of construction cost estimates and participation in value engineering during project
design, and successfully tracking and reporting construction costs, including line-item costs for
each bid package, fees, permits, reimbursable costs, CM fees, and all other project costs. 10
Points
SECTION 5 | Scheduling: Describe the primary scheduling techniques the firm uses and the
software you will employ to produce an effective construction schedule. Provide examples of
successful construction management and scheduling services provided on relevant projects.
Discuss in detail how you intend to enforce contract schedule compliance. 10 Points
11 RFQ: CM/GC Services – (Police Station Facility Project)
SECTION 6 | Relevant Experience: Include project name, project description, client reference
(including contact name and title, role on the project, email address, and telephone), project
budget, type of services provided, and other pertinent information for a minimum of three (3)
relevant project. Please focus on firm experience – do not include individual experience for
projects performed while individuals were employed by other firms. 40 Points
SECTION 7 | Local Experience: Also, describe your firm’s presence and past experience in Idaho,
including but not limited to, past projects completed in Idaho, employment of residents of
Idaho, other work performed in Idaho and corporate presence in Idaho. 30 Points
5.2 Evaluation of Respondent
Proposals will be evaluated based on the Respondent’s response and qualifications by a selection
committee that may include CITY employees and elected officials. Before a firm is selected, CITY may
conduct reference investigations or interviews with one or more Respondents as is necessary to
evaluate and determine the performance record and ability of the Respondents to perform the size and
type of work anticipated and to determine the quality of the service being offered. By submitting a
SOQ, the Respondent authorizes CITY to conduct reference investigations as needed and interview as
necessary.
5.3 Qualification Based Selection
Selection will be based on the procurement rules set forth in Idaho Code § 67-2320. Final selection is
made by the CITY Council. The CITY Council has the right to waive or alter submission requirements or to
reject any or all submissions, consistent with Idaho law. It is the Respondent’s responsibility to conform
to all applicable federal, state and local statutes or other applicable legal requirements. The information
provided herein is intended to assist Respondents in meeting applicable requirements but is not
exhaustive, and CITY will not be responsible for any failure by any Respondent to meet applicable
requirements.
5.4 Exhibits
A. RFQ Submittal Information Form
B. RFQ Waiver and Release Form
EXHIBIT A
Submittal Information Form
CONSTRUCTION MANAGER / GENERAL CONTRACTOR (CM/GC)
SERVICES: Police Station Facility Project
TO: City of Rexburg
Attn: Brandy Davis
35 N 1st E
Rexburg, ID 83440
FROM: Firm Name: ________________________________________________________________________
Mailing Address: ___________________________________________________________________
Physical Address: ___________________________________________________________________
Telephone: _________________________________ Fax: ____________________________________
E-mail Address: _
License Information: Idaho Public Works Contractor License # _______________________________
Idaho Public Works Construction Management License # ____________________________________
held by _____________________________, name of licensed CM for your firm.
(Please include a copy of each license behind this form. Also include a copy of your firms Certificate
of Authority, naming both your firm and the licensed CM for your firm.)
Surety Information: Please attach a project specific letter from your Surety.
Other Information:
Has your firm been insolvent or filed for bankruptcy within the last five years?
Has your firm has ever been denied insurance coverage or had coverage cancelled
over the last five years?
Has any current or former surety rejected a request by your firm for either a
payment and performance or labor and materials bond over the last five years?
If your response to any/all of these questions is “Yes”, please attach a written document describing,
in detail, each situation.
Firm’s officer responsible to CITY for CM/GC services contemplated by this RFQ:
SIGNATURE: X________________________________________________________________
Print Name / Title: _
Date: __________________________
□ Yes □ No
□ Yes □ No
□ Yes □ No
EXHIBIT B
RFQ Waiver and Release Form
(REQUIRED FOR SUBMISSION)
Firm Name: ___________________________________________________________________
The undersigned has read this waiver and release and fully accepts the CITY discretion and non-liability as
stipulated herein, and expressly for, but not limited to, CITY’s decision to proceed with a qualification-
based selection process in response to the Request for Qualifications (RFQ) to select a firm to supply
CM/GC services to CITY for the project.
A. Discretion of CITY: The firm or individual submitting a response to this CM/GC RFQ agrees
that CITY has the right to, unless contrary to applicable state law:
1) Modify or suspend any and all aspects of the process seeking SOQs and making any
decisions concerning this RFQ.
2) Obtain further information from any person, entity, or group regarding the
Respondent, and to ascertain the depth of Respondent’s capability and experience for
supplying CM/GC services and in any and all other respects to meet with and consult
with any Respondent or any other person, entity, or group;
3) Waive any formalities or defects as to form, procedure, or content with respect to
CITY’s RFQ to select a CM/GC firm and any response by any Respondent thereto;
4) Accept or reject any sealed SOQs received in response to the RFQ, including any sealed
SOQ submitted by the undersigned; or select any one SOQ over another in accordance
with the selection criteria;
5) Accept or reject all or any part of any materials or statements, including, but not
limited to, the nature and type of SOQ.
B. Non-Liability of CITY:
1) The undersigned agrees that CITY shall have no liability whatsoever of any kind or
character, directly or indirectly, by reason of all or any decision made at the discretion
of CITY as identified above.
2) The undersigned, including all team members, have carefully and thoroughly reviewed
the RFQ and has found it to be complete and free from ambiguities and sufficient for
their intended purpose.
Firm’s officer responsible to CITY for CM/GC services contemplated
by this RFQ:
SIGNATURE: X______________________________________________________________
Print Name / Title: _________________________________________________________________
Date: _________________________