Loading...
HomeMy WebLinkAboutbid_packet_-_quad_lighting_installation_prk-03-20BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project #PRK -03-20 2 Project # PRK-03-20 Table of Contents INVITATION FOR BIDS (White) INSTRUCTIONS TO BIDDERS (White) PROPOSAL FORMS (Blue) PROPOSAL BID BOND NOTICE OF AWARD (White) CONTRACT FORMS (Green) CONTRACT FOR CONSTRUCTION PAYMENT BOND PERFORMANCE BOND GENERAL FORMS (Yellow) NOTICE TO PROCEED CHANGE ORDER WORK CHANGE DIRECTIVE CERTIFICATE OF SUBSTANTIAL COMPLETION APPLICATION FOR PAYMENT ISWPC DIVISION 100 – STANDARD GENERAL CONDITION OF THE CONSTRUCTION CONTRACT (White) SUPPLEMENTARY CONDITIONS (White) SPECIAL PROVISIONS (White) SPECIFICATIONS 3 Project # PRK-03-20 INVITATION FOR BIDS Separate sealed bids for baseball quad electrical field lighting installation. will be received by the City of Rexburg, Idaho. The bids will be received at City Hall, 35 North 1st East Rexburg, ID 83440 until 3:00 P.M. on June 23, 2020 . Then at said office publicly opened and read aloud shortly thereafter. The project consists of replacing one city block of 8” ductile iron water pipe and related water utility work along with roadway restoration. The CONTRACT DOCUMENTS may be examined at the following location: Rexburg City Hall 35 North 1st East Rexburg, ID 83440 Upon a fee of $25.00, a copy of the CONTRACT DOCUMENTS may be obtained by contacting the City Clerk at the above address. They are also available online at http://rexburg.org/pages/rfps. Each Proposal must be submitted on the prescribed form and be accompanied by a certified cashier’s check or bid bond executed on the prescribed form payable to the City of Rexburg Idaho in an amount not less than 5% of the amount bid. The successful bidder will be required to furnish a performance and payment bond, each in the amount not less than 100% of the contract price. The City reserves the right to reject all proposals or any proposal not conforming to the intent and purpose of the Bid Documents. __________________________ ________________________________ June 5, 2020 to June 12, 2020 Keith Davidson P.E. Public Works Director/ City Engineer City of Rexburg ^TOP 4 Project # PRK-03-20 INSTRUCTIONS TO BIDDERS 1. FORMAT: The Contract Documents are divided into parts, divisions, and sections in keeping with accepted industry practice in order to separate categories of subject matter for convenient reference thereto. Generally, there has been no attempt to divide the Specification sections into the work performed by the various building trades, work by separate contractors, or work required for separate facilities in the project. Specifications are bound into these documents in the same order as they appear in the Table of Contents. Specification section numbers and the section page numbers are shown at the bottom of each page. Project Plans are bound separately from these Contract Documents. 2. COPIES OF BIDDING DOCUMENTS: Complete sets of bidding documents may be obtained from the City of Rexburg for the fee stated in the Invitation to Bid. Complete sets of bidding documents must be used in preparing bids; neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets of bidding documents. The Owner in making copies of the bidding documents available on the above terms does so only for the purpose of obtaining bids on the work and does not cover a license or grant for any other use. 3. FORM OF PROPOSAL: The proposal shall be made on the bidding schedules(s) bound herein. Additional copies are available from the City upon request. The complete Contract Document volume shall be enclosed in a sealed envelope bearing the name of the Bidder and name of the project. All blanks on the bid form must be completed in ink and be printed legibly. The Contractor is required to list all subcontractors for electrical, plumbing and mechanical as called for in the Bidders Proposal in order for the bid to be responsive. Bids by corporations must be executed in the corporate name by the president or a vice-president, or other corporate officer accompanied by evidence of authority to sign, and the corporate seal must be affixed and attested by the secretary or an assistant secretary. The corporate address and state of incorporation must be shown below the signatures. Bids by partnerships must be executed in the partnership name and signed by a partner whose title must appear under the signature and the official address of the partnership must be shown below the signature. All names must be printed below the signature. The bid shall contain an acknowledgment of receipt of all addenda (the numbers and dates of which must be filled in on the bid form). 4. DELIVERY OF PROPOSAL: 5 Project # PRK-03-20 The proposal shall be delivered by the time and to the place stipulated in the Invitation to Bid. It is the Bidder’s sole responsibility to see that his proposal is received in proper time. Any proposal received after the scheduled closing time for receipt of proposals will be returned to the Bidder unopened. Bids shall be enclosed in an opaque, sealed envelope and plainly marked with the project title (and if applicable, the designated portion of the project for which the bid is submitted), name and address of the Bidder, the license number of the Bidder, and accompanied by the bid security and other required documents. If the bid is sent through the mail or another delivery system, the sealed envelope shall be enclosed in a separate envelope with the notation “Bid Enclosed” plainly marked on the face of it and addressed to: City of Rexburg 35 North 1st East Rexburg, ID 83440 5. WITHDRAWAL OF PROPOSAL: The proposal may be withdrawn by the Bidder by means of a written request, signed by the Bidder or his properly authorized representative. Such written request must be delivered to the place stipulated in the Invitation to Bid for receipt of proposals prior to the scheduled closing time for receipt of proposals. 6. OPENING OF PROPOSALS: The proposals will be publicly opened and read at the time and place stipulated in the Invitation to Bid. 7. MODIFICATIONS AND ALTERNATIVE PROPOSALS: Unauthorized conditions, limitations, or provisions attached to a proposal will render it informal and may cause its rejection. The complete proposal forms shall be without interlineations, alterations, or erasures. Alternative proposals will not be considered unless called for. Oral, telephonic proposals or modifications will not be considered. Any bidder may modify his bid by telegraphic or written communication at any time prior to the scheduled closing time for receipt of bids, provided such communication is received by the Owner prior to the closing time. The telegraphic or written communication should not reveal the bid price; it should, however, state the addition or subtraction or other modification so that the final prices or terms will not be known by the Owner until the sealed bid is open. 8. DISCREPANCIES IN PROPOSALS: In the event there is more than one bid item in a bidding schedule, the Bidder shall furnish a price for all bid items in the schedule, and failure to do so will render the proposal informal and may cause its rejection. In the event there are unit price bid items in a bidding schedule and the “amount” indicated for a unit price bid item does not equal the product of the unit price and quantity, the unit price shall govern and the amount will be corrected accordingly. In the event there is more than one bid item in a 6 Project # PRK-03-20 bidding schedule and the total indicated for the schedule does not agree with the sum of the prices bid on the individual items, the prices bid on the individual items shall govern and the total for the schedule will be corrected accordingly. 9. PROPOSAL GUARANTEE: Each proposal shall be accompanied by a certified cashier’s check or Corporate bid bond in the amount stated in the Invitation to Bid. Other forms of Bonds will not be allowed. Said check or bond shall be made payable to the City of Rexburg and shall be given as a guarantee that the Bidder, if awarded the work, will enter into a contract within 10 calendar days after receipt of the contract from the Owner, and will furnish the necessary insurance certificates, faithful performance bond, and labor and material bond; each of said bonds to be in the amount stated in these Contract Documents. In case of refusal or failure to enter into said contract, the check or bid bond, as the case may be, shall be forfeited to the Owner. If the Bidder elects to furnish a bid bond as his proposal guarantee, he shall use the bid bond form bound herein, or one conforming substantially to it in form. 10. RETURN OF PROPOSAL GUARANTEE: Within 10 calendar days after award of the contract, the Owner will return the proposal guarantees accompanying such of the proposals as are not considered in making the award. All other proposal guarantees will be held until the contract has been finally executed. They will then be returned to the respective bidders whose proposals they accompany. 11. CONTRACT SECURITY: A Performance Bond and a Payment Bond, each in the amount of 100 percent of the contract price, with a corporate surety approved by the Owner will be required for the faithful performance of the contract. Attorneys-in-fact who sign Bid Bonds or Payment Bonds and Performance Bonds must file with each bond a certified and effective dated copy of their Power of Attorney. 7 Project # PRK-03-20 12. AWARD OF CONTRACT: The Owner will award the contract, if it is to be awarded, to the lowest responsive, responsible bidder submitting a bid for the selected alternative. Any such award will be made within 15 calendar days after the opening of the proposals, unless a longer waiting period before the award is expressly allowed in the Invitation to Bid, or is mutually agreed to between Owner and Bidder. A contract will be awarded for each schedule or combination of schedules of work as defined in the bid schedules. Owner reserves the right to reject any and all bids; to waiver any and all informalities not involving price, time or changes in the work, and to negotiate contract terms with the successful Bidder; and the right to disregard all nonconforming, nonresponsive, unbalanced, or conditional bids. Also, Owner reserves the right to reject the bid of any Bidder if Owner believes that it would not be in the best interest of the project to make an award to that Bidder, whether because the bid is not responsive or the Bidder is unqualified, of doubtful financial ability, or fails to meet any pertinent standard or criteria established by the Owner. The Owner may make such investigations as deemed necessary to determine the ability of the Bidder to perform the work and the Bidder shall furnish to the Owner all such information and data for this purpose as the Owner may request. The low Bidder shall supply the names and addresses of major material suppliers and subcontractors when required to do so by the Owner. 13. EXECUTION OF CONTRACT: The Bidder to whom the award is made shall execute a written contract with the Owner on the form of the agreement provided, shall secure all insurance, and shall furnish all certificates and bonds required by the specifications within ten calendar days after receipt of the Notice of Award from the Owner. Failure or refusal to enter into a contract as herein provided or to conform to any of the stipulated requirements in connection therewith shall be just cause for annulment of the award and the forfeiture of the proposal guarantee. If the successful Bidder refuses or fails to execute the contract, the Owner may award the contract to the second-lowest responsive responsible Bidder. If the second lowest responsive responsible Bidder refuses or failed to execute the contract, the Owner may award the contract to the third lowest responsive responsible Bidder. On the failure or refusal of such second or third lowest Bidder to execute the contract, such Bidders’ guarantees shall be likewise forfeited to the Owner. 14. DISQUALIFICATION OF BIDDERS: More than one proposal from an individual, firm, partnership, corporation, or association under the same or different names will not be considered. Reasonable grounds for believing that any Bidder is interested in more than one proposal for the work contemplated will cause the rejection of all proposals in which such Bidder is interested. If there is reason for believing the collusion exists among the Bidders, all bids will be rejected and none of the participants in such collusion will be considered in future proposals. 15. BIDDER’S EXAMINATION OF SITE: 8 Project # PRK-03-20 Before submitting a proposal, the Bidder shall carefully examine the Plans, Specifications, and other contract documents, and he shall visit the area for the intended construction. It will be assumed that the Bidder is familiar with existing site conditions and that he has a clear understanding of the requirements of the Contract regarding the furnishing of materials and performance of work. 16. BIDDER’S UNDERSTANDING: Each Bidder must inform himself of the conditions relating to the execution of the work, and it is assumed that he will inspect the construction site and make himself thoroughly familiar with all work to be completed and all existing conditions. Failure to do so will not relieve the successful Bidder of his obligation to enter into a contract and complete the contemplated work in strict accordance with the Contract Documents. It shall be the Bidder’s obligation to verify for himself and to his complete satisfaction all information concerning the site, subsurface conditions, utilities, and existing facilities. Bidders must satisfy themselves of the accuracy of the estimated quantities in the Bid Schedule by examination of the site and a review of the Plans and Specifications, including Addenda. After bids have been submitted, the Bidder shall not assert that there was a misunderstanding concerning the quantities of work or of the nature of the work to be done. Each Bidder shall inform himself of, and the Bidder awarded a contract shall comply with Federal, State and local laws; statutes, and ordinances relative to the execution of the work. This requirement includes, but is not limited to, protection of public and employee safety and health, environmental protection, the protection of natural resources, fire protection, burning and non-burning requirements, permits, fees, and similar subjects. 17. DOCUMENT INTERPRETATION: The Contract Documents governing the work proposed herein consist of the Plans and all material bound herewith. These Contract Documents are intended to mutually cooperate and to provide all details reasonably required for the execution of the proposed work. Any person contemplating the submission of a proposal shall have thoroughly examined all of the various parts of these documents, and should there be any doubt as to the meaning or intent of said Contract Documents or Plans, the Bidder should request of the Engineer, in writing, an interpretation thereof. Any interpretation or change in said Contract Documents will be made only in writing, in the form of Addenda to the documents, which will be furnished to all Bidders receiving a set of the documents. Bidders shall submit with their proposals, or indicate receipt of, all Addenda. The Owner will not be responsible for any other explanation or interpretations of said documents. Any Bidder who has objections needs clarification, or any requests for changes or modifications to these documents must make it known in writing and delivered to the Engineer no later than 12:00 noon on the day seven days prior to the scheduled bid opening. 18. LICENSE REQUIREMENTS: 9 Project # PRK-03-20 The public works project is not financed in part by Federal Aid Funds. All Contractors, Subcontractors and Specialty Contractors are required to have a current license as a Public Works Contractor in the State of Idaho in order to submit a bid or proposal on this project. 19. PREVAILING WAGE RATES: NONE 20. ENGINEER The Engineer for this project will be the City of Rexburg, Brett McDermott, City Engineer. 21. IDAHO PREFERENCE: Section 67-2348 Idaho Code, requires that any out of state Contractor submitting a bid in the State of Idaho be subject to the preference law of the state, in which his home office is located. ^TOP 10 Project # PRK-03-20 Proposal Proposal Bid Bond 11 Project # PRK-03-20 PROPOSAL Contract: BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project No.: PRK-03-20 To: THE HONORABLE MAYOR AND CITY COUNCIL OF THE CITY OF REXBURG: The undersigned, hereinafter called the Bidder, declares that the only persons or parties interested in this Proposal are those named herein; that this Proposal is in all respects fair and without fraud; that it is made without collusion with any official or employee of the City of Rexburg, Idaho; and that the Proposal is made without any connection or collusion with any person making another proposal on this contract. Bidder has carefully examined these Contract Documents; has personally inspected the site; has satisfied himself as to quantities of materials, items of equipment, and conditions of work involved. This Proposal is based upon the Contract Documents, which are hereto attached and are hereby made a part of this Proposal, and in the event of any conflict between this Proposal and the Contract documents, the terms of the latter shall be controlling. Proposal and Bid Bond Each proposal must be submitted on the prescribed form. The proposal must be accompanied by a Certified Check or Cashier's Check drawn on a bank in good standing or a Bid Bond issued by a Surety authorized to issue such bonds in the State of Idaho, all in an amount not less than Five Percent (5%) of the total amount bid. The Bid Bond shall be in substantially the same form as the sample bid bond included in the Contract Documents. Bidder agrees this bid may not be withdrawn for a period of Thirty (30) Calendar Days after the opening of bids. If this Proposal is accepted, bidder will execute the Contract with the City of Rexburg, in the form of contract attached herewith and will further deliver to the City of Rexburg, the Payment and Performance Bonds required herein within ten (10) days after receipt of notification of acceptance of his Proposal. Bid securities will be returned to unsuccessful bidders after the award of contract and to successful bidders upon execution of the required Contract Documents. It is agreed that the sum of five percent (5%) of bid, deposited herewith in. accordance with the conditions of the Contract Documents, may be retained by the City of Rexburg as liquidated damages as a fair measure of the damages that the City of Rexburg will sustain if Bidder fails or refuses to enter into the Contract for the work and to furnish the Payment and Performance Bonds as specified in the Contract Document. Certificates of Insurance The bidder further agrees that should his Proposal be accepted, he will furnish to the City a Certificate of Insurance, executed by insurance companies authorized to do insurance business in Idaho, certifying that policies of insurance as required by the Contract have been duly issued to the Bidder and its subcontractors where required. This paragraph applies to all insurance required by the Contract, including, but not limited to, Workmen's Compensation Insurance. Contract Time and Liquidated Damages 12 Project # PRK-03-20 The Bidder further agrees that should this Proposal be accepted, Bidder will complete installation of the lighting equipment in forty-five (45) calendar days from the notice to proceed. In the event the Bidder should fail to complete the work by the time limit or extended time limit agreed upon, liquidated damages shall be paid to the City of Rexburg, Idaho, at the rate of FIVE HUNDRED DOLLARS ($500.00) PER CALENDAR DAY until the work shall have been completed as provided by the Contract Documents. Bid The Bidder agrees that the foregoing prices represent a true measure of the labor and materials required to perform the work, including all allowances for overhead and profit, for each type and unit of work called for and that he will to the extent of his Proposal, furnish all machinery, tools and other equipment necessary for construction of this project, and do the work and furnish all materials necessary to complete the work in the manner, in the time and according to the methods as specified in the Contract Documents and required by the City Engineer thereunder. The City reserves the right to increase or decrease the various classes and types of work called for as best serves the interest of the City, provided a reasonable amount of additional time is allowed for performance of such additional work. The bidder will have no claim for costs associated with decreased work amounts. Additional work will be charged to the City only after being approved by the City Engineer and shall be comparably priced with the items in the Contract. In the event the Bidder performs additional work and no additional time is first agreed to in writing, then Bidder shall be deemed to have waived its right to additional time to perform such work. The Bidder further agrees to accept as full payment for the work herein proposed the amount computed under the provisions of the Contract Documents, and based on the foregoing unit price proposals, it being expressly understood that the listed quantities are used for purposes of bid comparison and evaluation only. BID SCHEDULE Bid Item Item Description Unit Amount 1 Install Pre-Purchased Lighting Equipment and Controls In Accordance with Supplier Recommendations LS 2 Provide and install all other panels, conduit, wires, junction boxes, etc. not included in Pre-Purchased Equipment Package, but required for a complete and functional installation. LS Total Written Total 13 Project # PRK-03-20 The name and signature of the authorizing Bidder who is submitting this Proposal is: Signature ______________________________________________ Written ________________________________________________ Who has an Idaho Public Works Contractors License No. And Type of _________________and doing business at _______________________________ (Street) ____________________________, __________________________________________________ (City) (State and zip code) which is the address to which all communication concerned with this Proposal and with the Contract shall be sent. The Bidder acknowledges receipt of the following Addenda Numbers: _____, _____, _____, _____, _____, _____, _____, _____, _____, _____, Bidder agrees that all addenda issued are hereby made part of the Contract Documents and that his Proposal includes all impacts resulting from said addenda. ACKNOWLEDGED BY: _______________________________________________________________________________ 14 Project # PRK-03-20 LIST OF SUBCONTRACTORS List below1 the name and business address of each subcontractor who will perform work under this contract in excess of one percent of the CONTRACTOR's total bid price, indicating the work to be performed and the percentage amount of the total contract to be done by such subcontractor. After the opening of Bids, no changes or substitutions will be allowed. Work to be Performed Subcontractor's License Number Percent of Total Contract Subcontractor's Name & Address2 Electrical2 Plumbing2 HVAC2 Mechanical2 Other (List) Other (List) Other (List) Notes: 1. Attach additional sheets, if required. 2. By State law, all Electrical, Plumbing, HVAC, and Mechanical subcontractors must be listed above or the bid will be non-responsive. If there is no subcontractor associated with a specific type of work, please write “None” on the associated line under Subcontractor’s Name & Address. SUBMITTED on , 2020. 15 Project # PRK-03-20 Idaho Contractor’s Registration # . Employer’s Tax ID No. . If Bidder is: An Individual By (Printed Individual's Name) (signature) doing business as Business address: Phone No. A Partnership By (Firm Name) (signature of general partner) Business address: Phone No. A Corporation By (Corporation Name) (state of incorporation) By: (signature of person authorized to sign) (title) Attest (secretary) Business Address: Phone No. Date of Qualification to do business is: A Joint Venture By (name) (signature) (address) By 16 Project # PRK-03-20 (name) (signature) (address) Phone Number and Address for receipt of official communications (Each joint venturer must sign. The manner of signing for each individual, partnership and corporation that is a party to the joint venture should be in the manner indicated above). NOTICE: In the event Bidder allows any subcontractor not listed above to perform work on the Project, Owner may terminate the Contract and Bidder shall forfeit all rights to complete the work and all right to compensation for work performed or materials supplied by such subcontractor. EXCEPTIONS: If the terms and conditions provided on the preceding pages cannot be met, bidders are instructed to note those terms and conditions with which they take exception and give a full explanation in the space below. IF NO EXCEPTIONS ARE TAKEN, WRITE "NONE". 17 Project # PRK-03-20 GENERAL INFORMATION Furnish the following information. Failure to comply with this requirement will render the Bid incomplete and may cause its rejection. Attach additional sheets as required. 1. Contractor's name and address (mail and business): 2. Contractor's telephone and fax numbers:( ) 3. Contractor's State License: Primary Classification State License No. Supplemental Classification held, if any: Bid Limit: 4. Number of years as a contractor in construction work of this type: 5. Names and titles of all officers of CONTRACTOR's firm: 6. Name of person who inspected site of proposed work for your firm: Name: Date of Inspection: Name, address, and telephone number of surety company and agent who will provide required bonds on this contract: Surety Company: Mailing Address: City, State, Zip: ____ Contact: Phone: ( ) ^TOP 18 Project # PRK-03-20 BID BOND BIDDER (Name and Address): _________________________________________________________________ _____________________________________________________________________ _____________________________________________________________________ SURETY (Name and Address of Principal Place of Business): _____________________________________________________________________ _____________________________________________________________________ _____________________________________________________________________ OWNER (Name and Address): _____________________________________________________________________ _____________________________________________________________________ _____________________________________________________________________ BID BID DUE DATE: _________________________ PROJECT (Brief Description Including Location): ___________________________________________________________________________________ ___________________________________________________________________________________ ___________________________________________________________________________________ BOND BOND NUMBER: _____________________________________ DATE (Not later than Bid due date): _______________________ PENAL SUM: ________________________________________ ________________________________ (Words) (Figures) IN WITNESS WHEREOF, Surety and Bidder, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Bid Bond to be duly executed on its behalf by its authorized officer, agent, or representative. BIDDER SURETY _______________________________________ (Seal) _____________________________________ (Seal) Bidder's Name and Corporate Seal Surety's Name and Corporate Seal By: ___________________________________ By: _________________________________ Signature and Title Signature and Title (Attach Power of Attorney) Attest: ________________________________ Attest: _______________________________ Signature and Title Signature and Title _____________________________________________________________________________ Note: (1) Above addresses are to be used for giving the required notice. (2) Any singular reference to Bidder, Surety, OWNER or another party shall be considered plural where applicable. 19 Project # PRK-03-20 1. Bidder and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to pay to OWNER upon default of Bidder the penal sum set forth on the face of this Bond. 2. The default of Bidder shall occur upon the failure of Bidder to deliver within the time required by the Bidding Documents (or any extension thereof agreed to in writing by OWNER) the executed Agreement required by the Bidding Documents and any performance and payment Bonds required by the Bidding Documents. 3. This obligation shall be null and void if: 3.1. OWNER accepts Bidder's Bid and Bidder delivers within the time required by the Bidding Documents (or any extension thereof agreed to in writing by OWNER) the executed Agreement required by the Bidding Documents and any performance and payment Bonds required by the Bidding Documents, or 3.2. All Bids are rejected by OWNER, or 3.3. OWNER fails to issue a Notice of Award to Bidder within the time specified in the Bidding Documents (or any extension thereof agreed to in writing by Bidder and, if applicable, consented to by Surety when required by paragraph 5 hereof). 4. Payment under this Bond will be due and payable upon default by Bidder and within 30 calendar days after receipt by Bidder and Surety of written notice of default from OWNER, which notice will be given with reasonable promptness, identifying this Bond and the Project and including a statement of the amount due. 5. Surety waives notice of and any and all defenses based on or arising out of any time extension to issue Notice of Award agreed to in writing by OWNER and Bidder, provided that the total time for issuing Notice of Award including extensions shall not in the aggregate exceed 120 days from Bid due date without Surety's written consent. 6. No suit or action shall be commenced under this Bond prior to 30 calendar days after the notice of default required in paragraph 4 above is received by Bidder and Surety and in no case later than one year after Bid due date. 7. Any suit or action under this Bond shall be commenced only in a court of competent jurisdiction located in the state in which the Project is located. 8. Notices required hereunder shall be in writing and sent to Bidder and Surety at their respective addresses shown on the face of this Bond. Such notices may be sent by personal delivery, commercial courier or by the United States Registered or Certified Mail, return receipt requested, postage pre-paid, and shall be deemed to be effective upon receipt by the party concerned. 9. The surety shall cause to be attached to this Bond a current and effective Power or Attorney evidencing the authority of the officer, agent or representative who executed this Bond on behalf of Surety to execute, seal and deliver such Bond and bind the Surety thereby. 10. This Bond is intended to conform to all applicable statutory requirements. Any applicable requirement of any applicable statute that has been omitted from this Bond shall be deemed to be included herein as if set forth at length. If any provision of this Bond conflicts with any applicable statute, then the provision of a said statute shall govern and the remainder of this Bond that is not in conflict therewith shall continue in full force and effect. 11. The term "Bid" as used herein includes a Bid, offer or proposal as applicable. ^TOP 20 Project # PRK-03-20 NOTICE OF AWARD DATE: __________________ TO: _______________________________ ADDRESS: ________________________ __________________________________ Contract: BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project No: PRK-03-20 You are notified that your Bid dated _____________________,2020. for the above Contract has been considered. You are the apparent Successful Bidder and have been awarded the Contract for _____________________________. The Contract Price of your Contract is ________________________________________. Three (3) copies of each of the proposed Contract Documents accompany this Notice of Award. You must comply with the following conditions precedent within 15 days of the date you receive this Notice of Award. 1. Deliver to the OWNER Three (3) fully executed counterparts of the Contract Documents. [Each of the Contract Documents must bear your signature on Contract – pg 4.] 2. Deliver with the executed Contract Documents the Contract security (Payment and Performance Bonds) as specified. 3. (List other conditions precedent). Failure to comply with these conditions within the time specified will entitle OWNER to consider your Bid in default, to annul this Notice of Award and to declare your Bid security forfeited. Within ten days after you comply with the above conditions, OWNER will return to you one fully executed counterpart of the Contract Documents. Jerry L. Merrill By: __________________________________________________________________ Mayor, City of Rexburg ^TOP 21 Project # PRK-03-20 Contract Forms Contract for Construction Performance Bond Payment Bond 22 Project # PRK-03-20 CONTRACT FOR CONSTRUCTION For: BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project No.: PRK-03-20 THIS CONTRACT, made and entered into this _____day of ______________, 2020, by and between the City of Rexburg, Idaho, hereinafter called City, ____________________, hereinafter called Contractor; WITNESSETH THAT, the City and the Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows: Contract Documents Contractor agrees, at his own proper cost and expense, to do all the work and furnish all the materials, tools, labor and all appliances, machinery, and appurtenances for the construction of the Project in accordance with the Proposal made by the Contractor on the _____ day of ______________, 2020, all in full compliance with the Contract Documents referred to herein. The "INVITATION FOR BIDS", the signed copy of the "PROPOSAL", the "SPECIAL PROVISIONS", and the fully executed "PAYMENT BOND" and "PERFORMANCE BOND" are hereby referred to and by reference all made a part of this Contract, as fully and completely as if the same were fully set forth herein. Contract Time and Payment Contractor agrees to complete the work within the time specified herein and to accept as full payment for all work, materials or services rendered on or delivered to the Project, an amount determined by the unit price method set forth in the Contract Documents and the Proposal, or the lump sum amount set forth in the Proposal. All work contemplated in the Proposal and the Contract Documents will be completed within forty-five (45) calendar days from the notice to proceed for substantial completion of the Notice to Proceed. Contract Execution and Bonds The Contractor agrees to execute this Contract and to deliver to the City of Rexburg, security for faithful performance of the Contract in the amount of one hundred percent (100%) of the contract amount and security for the protection of persons supplying labor or materials for the Contract in the amount of one hundred percent (100%) of the contract amount within ten (10) days after receipt of notification of acceptance of his Proposal. Such security may be in the form of a Certified Check or Cashier's Check drawn on a bank in good standing; Performance Bond 23 Project # PRK-03-20 and Payment Bond in the form specified in the Contract Documents and issued by a Surety authorized to issue such bonds in the State of Idaho. Certificates of Insurance Contractor agrees to furnish to the City, Certificate or Certificates of Insurance, executed by insurance companies authorized to do insurance business in Idaho, certifying that policies of insurance as required by the Contract have been duly issued to the Contractor and its subcontractors where required. This paragraph applies to all insurance required by the Contract, including, but not limited to, Workmen's Compensation Insurance. Payment of Taxes. Excises and License Fees Pursuant to the provisions of Section 63-1503 of the Idaho Code, the Contractor, in consideration of securing the business of erecting or constructing public works in the State of Idaho, recognizing that the business in which the Contractor is engaged is of a transitory character, and that in the pursuit thereof, the Contractor's property used therein may be without the State of Idaho when taxes, excises, or license fees to which the Contractor is liable to become payable, agrees: a) To pay promptly when due all taxes (other than on real property), excises, and license fees due to the State of Idaho, its subdivisions, and municipal and quasi-municipal corporations therein, accrued or accruing during the term of this Contract, whether or not the same shall be payable at the end of such term; b) That if the said taxes, excises, and license fees are not payable at the end of said term, but liability for the payment thereof exists, even though the same constitute liens upon his property, to secure the same to the satisfaction of the respective officers charged with the collection thereof; c) That, in the event of the Contractor's default in the payment or securing of such taxes, excises, and license fees, to consent that the Owner may withhold from any payment due the Contractor under the Contract the estimated amount of such accrued and accruing taxes, excises, and license fees for the benefit of all taxing units to which said Contractor is liable; d) That pursuant to the provisions of Section 63-1504 of the Idaho Code, the Contractor shall furnish the Owner evidence that the Contractor has paid all taxes, excises, and license fees due to the State of Idaho and its taxing units, due and payable during the term of the Contract for such construction, and that the Contractor has secured all such taxes, excises and license fees liability for the payment of which has accrued during the term of such Contract, notwithstanding that they may not yet be due or payable. 24 Project # PRK-03-20 Applications for Payments If Contractor faithfully performs the work herein embraced, in accordance with the Contract Documents, the City agrees to pay to the Contractor the amounts set forth in the Proposal, and the Contract Documents, in the manner and at the times provided in the Contract Documents. The City must receive a Public Works Contract Tax Release fully executed by the State of Idaho, Department of Revenue and Taxation prior to payment of retainage to the Contractor. Liquidated Damages In the event the Contractor fails to complete the work within the time limit or extended time limit agreed upon, as more particularly set forth in the Contract Documents, liquidated damages shall be paid to the City of Rexburg, Idaho, at the rate of FIVE HUNDRED DOLLARS ($500.00) PER CALENDAR DAY until the work has been finished as provided in the Contract Documents. Contractor acknowledges that such amount represents a fair and reasonable estimate of the damages Owner will suffer in the event of any delay in the performance of the work and that such amount does not constitute a penalty. Contractor further agrees that in the event Owner contributes to any delay, such liquidated damages shall be reduced only by the number of days fairly apportioned to such owner-caused delay, and the owner may assess and collect liquidated damages for all remaining delay caused by Contractor. Warranty The Contractor warrants all defects in the workmanship or materials performed or furnished under this Contract for which there are no specifications or specific provisions in the Contract Documents for a period of one (1) year after the acceptance thereof by the City. (Cont. on next page) 25 Project # PRK-03-20 IN WITNESS WHEREOF, the parties hereto, each herewith subscribes the same this ____ day of _________, 2020. CITY OF REXBURG, IDAHO (SEAL) __________________________________ Mayor Attest:____________________________ City Clerk __________________________________ (SEAL) Contractor __________________________________ (Signature) __________________________________ (Title) Attest: ___________________________ (Secretary) __________________________________ (Witness) _______________________________________________________________________ (Complete business address) ^TOP 26 Project # PRK-03-20 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. _____________________________________________________________________________________________ CONTRACTOR (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (Name and Address): CONTRACT Date: Amount: Description (Name and Location): BOND Date (Not earlier than Contract Date): Amount: Modifications to this Bond Form: Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: _____________________________________ Signature: ___________________________ Name and Title: Name and Title: (Attach Power of Attorney) (Space is provided below for signatures of additional parties if required.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: _____________________________________ Signature: ___________________________ Name and Title: Name and Title: EJCDC No. 1910-28-B (1996 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. 27 Project # PRK-03-20 1. The CONTRACTOR and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the OWNER to pay for labor, materials, and equipment furnished for use in the performance of the Contract, which is incorporated herein by reference. 2. With respect to the OWNER, this obligation shall be null and void if the CONTRACTOR: 2.1.Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2.Defends, indemnifies and holds harmless the OWNER from all claims, demands, liens or suits by any person or entity who furnished labor, materials or equipment for use in the performance of the Contract, provided the OWNER has promptly notified the CONTRACTOR and the Surety (at the addresses described in paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the CONTRACTOR and the Surety, and provided there is no OWNER Default. 3. With respect to Claimants, this obligation shall be null and void if the CONTRACTOR promptly makes payment, directly or indirectly, for all sums due. 4. The Surety shall have no obligation to Claimants under this Bond until: 4.1.Claimants who are employed by or have a direct contract with the CONTRACTOR have given notice to the Surety (at the addresses described in paragraph 12) and sent a copy, or notice thereof, to the OWNER, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2. Claimants who do not have a direct contract with the CONTRACTOR: 1.Have furnished written notice to the CONTRACTOR and sent a copy, or notice thereof, to the OWNER, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and 2.Have either received a rejection in whole or in part from the CONTRACTOR or not received within 30 days of furnishing the above notice any communication from the CONTRACTOR by which the CONTRACTOR had indicated the claim will be paid directly or indirectly; and 3.Not having been paid within the above 30 days, have sent a written notice to the Surety and sent a copy, or notice thereof, to the OWNER, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the CONTRACTOR. 5. If a notice required by paragraph 4 is given by the OWNER to the CONTRACTOR or to the Surety, that is sufficient compliance. 6. When the Claimant has satisfied the conditions of paragraph 4, the Surety shall promptly and at the Surety's expense take the following actions: 6.1.Send an answer to the Claimant, with a copy to the OWNER, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2.Pay or arrange for payment of any undisputed amounts. 7. The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8. Amounts owed by the OWNER to the CONTRACTOR under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, under any Performance Bond. By the CONTRACTOR furnishing and the OWNER accepting this Bond, they agree that all funds earned by the CONTRACTOR in the performance of the Contract are dedicated to satisfying obligations of the CONTRACTOR and the Surety under this Bond, subject to the OWNER's priority to use the funds for the completion of the Work. 9. The Surety shall not be liable to the OWNER, Claimants or others for obligations of the CONTRACTOR that are unrelated to the Contract. The OWNER shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10. The Surety hereby waives notice of any change, including changes of time, to the Contractor to related Subcontracts, purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the Work or part of the Work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by paragraph 4.1 or paragraph 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, the OWNER or the CONTRACTOR shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice by Surety, the OWNER or the CONTRACTOR, however, accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. When this Bond has been furnished to comply with a statutory or another legal requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or another legal requirement shall be deemed incorporated herein. The intent is, that this Bond shall be construed as a statutory Bond and not as a common law bond. 14. Upon request of any person or entity appearing to be a potential beneficiary of this Bond, the CONTRACTOR shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15. DEFINITIONS 15.1.Claimant: An individual or entity having a direct contract with the CONTRACTOR or with a Subcontractor of the CONTRACTOR to furnish labor, materials or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Contract, architectural and engineering services required for performance of the Work of the CONTRACTOR and the CONTRACTOR's Subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2.Contract: The agreement between the OWNER and the CONTRACTOR identified on the signature page, including all Contract Documents and changes thereto. 15.3.OWNER Default: Failure of the OWNER, which has neither been remedied nor waived, to pay the CONTRACTOR as required by the Contractor to perform and complete or comply with the other terms thereof. ^TOP 28 Project # PRK-03-20 Performance Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. _____________________________________________________________________________________________ CONTRACTOR (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (Name and Address): CONTRACT Date: Amount: Description (Name and Location): BOND Date (Not earlier than Contract Date): Amount: Modifications to this Bond Form: Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Performance Bond to be duly executed on its behalf by its authorized officer, agent or representative. CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: _______________________________ Signature: __________________________ Name and Title: Name and Title: (Attach Power of Attorney) (Space is provided below for signatures of additional parties if required.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corp. Seal) Company: (Corp. Seal) Signature: _______________________________ Signature: __________________________ Name and Title: Name and Title: 29 Project # PRK-03-20 1. The CONTRACTOR and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Contract, which is incorporated herein by reference. 2. If the CONTRACTOR performs the Contract, the Surety and the CONTRACTOR have no obligation under this Bond, except to participate in conferences as provided in paragraph 3.1. 3. If there is no OWNER Default, the Surety's obligation under this Bond shall arise after: 3.1.The OWNER has notified the CONTRACTOR and the Surety at the addresses described in paragraph 10 below, that the OWNER is considering declaring a CONTRACTOR Default and has requested and attempted to arrange a conference with the CONTRACTOR and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Contract. If the OWNER, the CONTRACTOR, and the Surety agree, the CONTRACTOR shall be allowed a reasonable time to perform the Contract, but such an agreement shall not waive the OWNER's right, if any, subsequently to declare a CONTRACTOR Default; and 3.2.The OWNER has declared a CONTRACTOR Default and formally terminated the CONTRACTOR's right to complete the Contract. Such CONTRACTOR Default shall not be declared earlier than twenty days after the CONTRACTOR and the Surety has received notice as provided in paragraph 3.1; and 3.3.The OWNER has agreed to pay the Balance of the Contract Price to: 3.3.1. The Surety in accordance with the terms of the Contract; 3.3.2Another contractor selected pursuant to paragraph 4.3 to perform the Contract. 4. When the OWNER has satisfied the conditions of paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 4.1.Arrange for the CONTRACTOR, with the consent of the OWNER, to perform and complete the Contract; or 4.2.Undertake to perform and complete the Contract itself, through its agents or through independent contractors; or 4.3.Obtain bids or negotiated proposals from qualified contractors acceptable to the OWNER for a contract for performance and completion of the Contract, arrange for a contract to be prepared for execution by the OWNER and the contractor selected with the OWNER's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the Bonds issued on the Contract, and pay to the OWNER the amount of damages as described in paragraph 6 in excess of the Balance of the Contract Price incurred by the OWNER resulting from the CONTRACTOR Default; or 4.4.Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances; 4.4.1After investigation, determine the amount for which it may be liable to the OWNER and, as soon as practicable after the amount is determined, tender payment therefor to the OWNER; or 4.4.2Deny liability in whole or in part and notify the OWNER citing reasons therefor. 5. If the Surety does not proceed as provided in paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the OWNER to the Surety demanding that the Surety perform its obligations under this Bond, and the OWNER shall be entitled to enforce any remedy available to the OWNER. If the Surety proceeds as provided in paragraph 4.4, and the OWNER refuses the payment tendered or the Surety has denied liability, in whole or in part, without further notice the OWNER shall be entitled to enforce any remedy available to the OWNER. 6. After the OWNER has terminated the CONTRACTOR's right to complete the Contract, and if the Surety elects to act under paragraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the OWNER shall not be greater than those of the CONTRACTOR under the Contract, and the responsibilities of the OWNER to the Surety shall not be greater than those of the OWNER under the Contract. To a limit of the amount of this Bond, but subject to commitment by the OWNER of the Balance of the Contract Price to mitigation of costs and damages on the Contract, the Surety is obligated without duplication for: 6.1.The responsibilities of the CONTRACTOR for correction of defective Work and completion of the Contract; 6.2.Additional legal, design professional and delay costs resulting from the CONTRACTOR's Default, and resulting from the actions or failure to act of the Surety under paragraph 4; and 6.3.Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non-performance of the CONTRACTOR. 7. The Surety shall not be liable to the OWNER or others for obligations of the CONTRACTOR that are unrelated to the Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the OWNER or its heirs, executors, administrators, or successors. 8. The Surety hereby waives notice of any change, including changes of time, to the Contractor to related subcontracts, purchase orders, and other obligations. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the Work is located and shall be instituted within two years after CONTRACTOR Default or within two years after the CONTRACTOR ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 10. Notice to the Surety, the OWNER or the CONTRACTOR shall be mailed or delivered to the address shown on the signature page. 11. When this Bond has been furnished to comply with a statutory or another legal requirement in the location where the Contract was be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted here from and provisions conforming to such statutory or another legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12. Definitions. 12.1Balance of the Contract Price: The total amount payable by the OWNER to the CONTRACTOR under the Contract after all proper adjustments have been made, including allowance to the CONTRACTOR of any amounts received or to be received by the OWNER in settlement of insurance or other Claims for damages to which the CONTRACTOR is entitled, reduced by all valid and proper payments made to or on behalf of the CONTRACTOR under the Contract. 12.2.Contract: The agreement between the OWNER and the CONTRACTOR identified on the signature page, including all Contract Documents and changes thereto. 12.3.CONTRACTOR Default: Failure of the CONTRACTOR, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Contract. 12.4. OWNER Default: Failure of the OWNER, which has neither been remedied nor waived, to pay the CONTRACTOR as required by the Contractor to perform and complete or comply with the other terms thereof. ^TOP 30 Project # PRK-03-20 General Forms Notice to Proceed Change Order Work Change Directive Certificate of Substantial Completion Application for Payment 31 Project # PRK-03-20 NOTICE TO PROCEED Date: _________________ TO: _________________________________ ADDRESS: ___________________________ _____________________________________ Contract: BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project No: PRK-03-20 You are notified that the Contract Times under the above contract will commence to run on ________________. By that date, you are to start performing your obligations under the Contract Documents. All work contemplated in the Proposal and the Contract Documents will be completed by ________________________. In accordance with Article 4 of the Agreement the date of Substantial Completion is ___________________________and the date of readiness for final payment is __________________________. Before you may start any Work at the Site, paragraph 2.01.B of the General Conditions provides that you and Owner must each deliver to the other (with copies to Engineer and other identified additional insureds) certificates of insurance which each is required to purchase and maintain in accordance with the Contract Documents. Also, before you may start any Work at the Site, you must ________________________________________________________________________ ________________________________________________________________________ City of Rexburg (OWNER) By: _________________________________________________________________ (AUTHORIZED SIGNATURE) Mayor (TITLE) ^TOP 32 Project # PRK-03-20 CHANGE ORDER No. _________ DATE OF ISSUANCE : ___________________ EFFECTIVE DATE: __________________ OWNER: City of Rexburg CONTRACTOR: Contract: Project: OWNER's Contract No.: ENGINEER's Contract No. __________NA_____________ ENGINEER: You are directed to make the following changes in the Contract Documents: Description: Reason for Change Order: Attachments: CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIMES: Original Contract Price Original Contract Times: Substantial Completion: __________________________ Ready for final payment: __________________________ (days or dates) Net Increase (Decrease) from previous Change Orders No. ___ to ___: $______________________ Net change from previous Change Orders No. ___ to No. ___: Substantial Completion: __________________________ Ready for final payment: __________________________ (days) Contract Price prior to this Change Order: Contract Times prior to this Change Order: Substantial Completion: __________________________ Ready for final payment: __________________________ (days or dates) Net decrease of this Change Order: __________________________ Net increase (decrease) this Change Order: Substantial Completion: __________________________ Ready for final payment: __________________________ (days) Contract Price with all approved Change Orders: Contract Times with all approved Change Orders: Substantial Completion: __________________________ Ready for final payment: __________________________ (days or dates) APPROVED: ACCEPTED: By: _______________________ By: ______________________ OWNER (Authorized Signature) CONTRACTOR (Authorized Signature) Date: ______________________ Date: _____________________ 33 Project # PRK-03-20 CHANGE ORDER INSTRUCTIONS ______________________________________________________________________________ A. GENERAL INFORMATION This document was developed to provide a uniform format for handling contract changes that affect Contract Price or Contract Times. Changes that have been initiated by a Work Change Directive must be incorporated into a subsequent Change Order if they affect Price or Times. Changes that affect Contract Price or Contract Times should be promptly covered by a Change Order. The practice of accumulating Change Orders to reduce the administrative burden may lead to unnecessary disputes. If Milestones have been listed in the Agreement, any effect of a Change Order thereon should be addressed. For supplemental instructions and minor changes not involving a change in the Contract Price or Contract Times, a Field Order should be used. B. COMPLETING THE CHANGE ORDER FORM Engineer normally initiates the form, including a description of the changes involved and attachments based upon documents and proposals submitted by Contractor, or requests from Owner, or both. Once Engineer has completed and signed the form, all copies should be sent to Owner or Contractor for approval, depending on whether the Change Order is a true order to the Contractor or the formalization of a negotiated agreement for a previously performed change. After approval by one contracting party, all copies should be sent to the other party for approval. The engineer should make the distribution of executed copies after approval by both parties. If a change only applies to price or to times, cross out the part of the tabulation that does not apply. ^TOP 34 Project # PRK-03-20 WORK CHANGE DIRECTIVE No. __________________ DATE OF ISSUANCE _________________ EFFECTIVE DATE ___________________ OWNER: _____________________________________________________________________________________ CONTRACTOR: ______________________________________________________________________________ Contract: _____________________________________________________________________________________ Project: ______________________________________________________________________________________ OWNER's Contract No. ___________________ ENGINEER's Project No. _________________ You are directed to proceed promptly with the following change(s): Description: Purpose of Work Change Directive: Attachments: (List documents supporting change) If OWNER or CONTRACTOR believe that the above change has affected Contract Price any Claim for a Change Order based thereon will involve one or more of the following methods as defined in the Contract Documents. Method of determining change in Contract Price: □ Unit Prices □ Lump Sum □ Cost of the Work ______________________ Estimated increase (decrease) in Contract Price: $_____________________________________. If the change involves an increase, the estimated amount is not to be exceeded without further authorization. Estimated increase (decrease) in Contract Times: Substantial Completion: ______ days; Ready for final payment: ______ days. ______________________________________________________________________________ AUTHORIZED: _______________________________________ OWNER By: ___________________________________ EJCDC No. 1910-8-F (1996 Edition) Prepared by the Engineers Joint Contract Documents Committee and endorsed by The Associated General Contractors of America and the Construction Specifications Institute. 35 Project # PRK-03-20 WORK CHANGE DIRECTIVE INSTRUCTIONS _____________________________________________________________________________ A. GENERAL INFORMATION This document was developed for use in situations involving changes in the Work which, if not processed expeditiously, might delay the Project. These changes are often initiated in the field and may affect the Contract Price or the Contract Times. This is not a Change Order, but only a directive to proceed with Work that may be included in a subsequent Change Order. For supplemental instructions and minor changes not involving a change in the Contract Price or the Contract Times, a Field Order should be used. B. COMPLETING THE WORK CHANGE DIRECTIVE FORM Engineer initiates the form, including a description of the items involved and attachments. Based on conversations between Engineer and Contractor, Engineer completes the following: METHOD OF DETERMINING CHANGE, IF ANY, IN CONTRACT PRICE: Mark the method to be used in determining the final cost of Work involved and the estimated net effect on the Contract Price. If the change involves an increase in the Contract Price and the estimated amount is approached before the additional or changed Work is completed, another Work Change Directive must be issued to change the estimated price or Contractor may stop the changed Work when the estimated time is reached. If the Work Change Directive is not likely to change the Contract Price, the space for the estimated increase (decrease) should be marked "Not Applicable". Once Engineer has completed and signed the form, all copies should be sent to Owner for authorization because Engineer alone does not have authority to authorize changes in Price or Times. Once authorized by Owner, a copy should be sent by Engineer to Contractor. Price and Times may only be changed by Change Order signed by Owner and Contractor with Engineer's recommendation. Paragraph 10.03.A.2 of the General Conditions require that a Change Order is initiated and processed to cover any undisputed sum or amount of time for Work actually performed pursuant to this Work Change Directive. Once the Work covered by this directive is completed or final cost and times are determined, Contractor should submit documentation for inclusion in a Change Order. THIS IS A DIRECTIVE TO PROCEED WITH A CHANGE THAT MAY AFFECT THE CONTRACT PRICE OR CONTRACT TIMES. A CHANGE ORDER, IF ANY, SHOULD BE CONSIDERED PROMPTLY. ^TOP 36 Project # PRK-03-20 CERTIFICATE OF SUBSTANTIAL COMPLETION DATE OF ISSUANCE ____________________ OWNER: _____________________________________________________________________________________ CONTRACTOR: ______________________________________________________________________________ Contract: _____________________________________________________________________________________ Project: ______________________________________________________________________________________ OWNER's Contract No. ___________________ ENGINEER's Project No. __________________________ This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To_____________________________________________________________________________ OWNER And To _________________________________________________________________________ CONTRACTOR The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR, and ENGINEER, and that Work is hereby declared to be substantially complete in accordance with the Contract Documents on ______________________________ DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within _______ days of the above date of Substantial Completion. EJCDC No. 1910-8-D (1996 Edition) Prepared by the Engineers' Joint Contract Documents Committee and endorsed by The Associated General Contractors of America and the Construction Specifications Institute. 37 Project # PRK-03-20 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties and guarantees shall be as follows: OWNER: _____________________________________________________________________ _____________________________________________________________________________ _____________________________________________________________________________ CONTRACTOR: _______________________________________________________________ ______________________________________________________________________________ ______________________________________________________________________________ The following documents are attached to and made a part of this Certificate: [For items to be attached see definition of Substantial Completion as supplemented and other specifically noted conditions precedent to achieving Substantial Completion as required by Contract Documents.] This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR's obligation to complete the Work in accordance with the Contract Documents. Executed by ENGINEER on _______________________ Date ___________________________________________ ENGINEER By: __________________________________________ (Authorized Signature) CONTRACTOR accepts this Certificate of Substantial Completion on ________________________ Date __________________________________________ CONTRACTOR By: __________________________________________ (Authorized Signature) OWNER accepts this Certificate of Substantial Completion on _______________________ Date _______________________________________ OWNER By: _______________________________________ (Authorized Signature) ^TOP 38 Project # PRK-03-20 APPLICATION FOR PAYMENT NO. ________ To: _________________________________________________________________________________(OWNER) From: _________________________________________________________________________(CONTRACTOR) Contract: _____________________________________________________________________________________ Project: ______________________________________________________________________________________ OWNER's Contract No.: _____________________ ENGINEER's Project No.: _____________________________ For Work accomplished through the date of: ____________________________ 1. Original Contract Price: $_____________________ 2. Net change by Change Orders and Written Amendments (+ or -): $_____________________ 3. Current Contract Price (1 plus 2): $_____________________ 4. Total completed and stored to date: $_____________________ 5. Retainage (per Agreement): _____% of completed Work: $____________________ _____% of stored material: $____________________ Total Retainage: $_____________________ 6. Total completed and stored to date less retainage (4 minus 5): $_____________________ 7. Less previous Application for Payments: $_____________________ 8. DUE THIS APPLICATION (6 MINUS 7): $_____________________ Accompanying Documentation: Schedule of Values CONTRACTOR'S Certification: The undersigned CONTRACTOR certifies that (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied on account to discharge CONTRACTOR’s legitimate obligations incurred in connection with Work covered by prior Applications for Payment numbered 1 through _____ inclusive; (2) title of all Work, materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all Liens, security interests and encumbrances (except such as are covered by a Bond acceptable to OWNER indemnifying OWNER against any such Lien, security interest or encumbrance); and (3) all Work covered by this Application for Payment is in accordance with the Contract Documents and not defective. Dated ______________________ _______________________________________________________________ CONTRACTOR By: State of ______________________________ County of ____________________________ Subscribed and sworn to before me this _____ day of __________________, ________ ____________________________________ Notary Public My Commission expires: _______________ Payment of the above AMOUNT DUE THIS APPLICATION is recommended. Dated ______________________ ______________________________________________________________ ENGINEER By: EJCDC No. 1910-8-E (1996 Edition) Prepared by the Engineers Joint Contract Documents Committee and endorsed by The Associated General Contractors of America and the Construction Specification Institute. 39 Project # PRK-03-20 APPLICATION FOR PAYMENT INSTRUCTIONS ______________________________________________________________________________ A. GENERAL INFORMATION The sample form of Application for Payment is intended as a guide only. Many projects require a more extensive form with space for numerous items, descriptions of Change Orders, identification of variable quantity adjustments, a summary of materials and equipment stored at the site and other information. It is expected that a separate form will be developed by Engineer and Contractor at the time Contractor's Application for Payment is finalized. Note also that the format for retainage must be changed if the Contract permits (or the law provides), and Contractor elects to deposit securities in lieu of retainage. Refer to Article 14 of the General Conditions for provisions concerning payments to Contractor. B. COMPLETING THE FORM The Schedule of Values submitted and approved as provided in paragraphs 2.05.B.3 and 2.07 of the General Conditions, should be reproduced as appropriate in the space indicated on the Application for Payment form. Note that the cost of materials and equipment is often listed separately from the cost of installation. Also, note that each Unit Price is deemed to include Contractor's overhead and profit. All Change Orders affecting the Contract Price should be identified and included in the Schedule of Values as required for progress payments. The form is suitable for use in the Final Application for Payment as well as for Progress Payments; however, the required accompanying documentation is usually more extensive for final payment. All accompanying documentation should be identified in the space provided on the form. C. LEGAL REVIEW All accompanying documentation of a legal nature, such as Lien waivers, should be reviewed by an attorney, and Engineer should so advise Owner ^TOP 40 Project # PRK-03-20 ISWPC DIVISION 100 – STANDARD GENERAL CONDITION OF THE CONSTRUCTION CONTRACT https://www.rexburg.org/sites/default/files/fileattachments/public_works/page/10759/2017_edition_i spwc.pdf ^TOP 41 Project # PRK-03-20 SUPPLEMENTARY CONDITIONS INTRODUCTORY STATEMENT These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction and other provisions of the Contract Documents as indicated below. All provisions which are not so amended or supplemented remain in full force and effect. The terms used in these Supplementary Conditions which are defined in the Standard General Conditions of the Construction Contract have the meanings assigned to them in the General Conditions. SC 1. Add the following term to the definition to Article 1: Contingency amount – Moneys allocated by OWNER but no payable to CONTRACTOR for the WORK described in the Contract Documents. SC 2. Add the following to paragraph 2.6.1 2.6.1 This estimated progress schedule shall be in the form of the bar graph or CPM, in reproducible form. The OWNER shall approve the form and the content for adequacy. SC 3.7 Add paragraph 3.7 to the General Conditions as follows: Priority of Provisions of Contract Documents: 3.7 In the event that any provision of any one Contract Document conflicts with the provision of another Contract, the provision in that Contract Document first listed below shall govern, except as otherwise specifically stated: 1. Agreement 2. Addenda to Contract Documents 3. Remaining Legal and Procedural Documents a. Bid Form b. Invitation to Bid c. Instructions to Bidders 4. Detailed Specification Requirements (Divisions 1 thru 16 inclusive). 42 Project # PRK-03-20 5. Drawings 6. General Conditions of the Contract 7. Bonds a. Performance Bond b. Labor and Materials Payment Bond c. Proposal Guaranty SC 5.3 The limits of liability for the insurance required by paragraph 5.3 of the General Conditions shall provide coverage for not less than the following amounts or greater where required by Laws and Regulations: 5.3.1 and 5.3.2 Workers’ Compensation, etc., under paragraphs 5.3.1 and 5.3.2 of the General Conditions 1. State: Statutory 2. Applicable Federal (e.g. Statutory Longshoreman’s): 3. Employer’s Liability Statutory 5.3.3, 5.3.4 and 5.3.6 Comprehensive General Liability (under paragraphs 5.13 through 5.3.6 if the General Conditions): 1. Bodily Injury (including completed operations products liability): $1,000,000 Each Occurrence $1,000,000 Annual Aggregate Property Damage $1,000,000 Each Occurrence $1,000,000 Annual Aggregate or combined single limit of $3,000,000 2. Property Damage Liability Insurance will provide Explosion, Collapse, and Underground coverage where applicable. 3. Personal Injury, with employment exclusion, deleted: $1,000,000 Annual Aggregate 5.3.7 Comprehensive Automobile Liability: Bodily Injury: 3,000,000 Each Person 3,000,000 Each Occurrence 43 Project # PRK-03-20 Property Damage: Statutory Each Occurrence or combined single limit $1,000,000 Add the following paragraph: 5.3.8 CONTRACTOR’S Liability Insurance shall specifically cover claims under GC 5,3.6 for damages caused by CONTRACTOR’S equipment, material, tools, and property of OWNER or other contractors employed on the project by the OWNER. 5.3.8 The CONTRACTOR’S liability insurance shall include the City of Rexburg under the policy for this project only. SC 5.4 1. Bodily Injury $3,000,000 Each Occurrence $3,000,000 Annual Aggregate SC 6.8 Add two new paragraphs immediately after paragraph 6.8.2 of the General Conditions which is to read as follows: 6.8.3 CONTRACTOR shall not be permitted, without the express written authorization of OWNER, to subcontract more than fifty percent (50%) of the CONTRACTOR’S work. Said percentage shall be computed by dividing the summation of the total cost for all the subcontracted work by the CONTRACTOR’S price or the summation of all total man hours for all subcontracted work by the summation of all total man-hours required for CONTRACTOR’S total man hours, whichever is less. SC 6.1.3 Amend the first sentence with the following: 6.1.3 Unless otherwise provided in Contract CONTRACTOR shall obtain and pay Administrative Provisions, permits, and licenses. SC 6.19 Following the first paragraph, add the following: CONTRACTOR shall provide the OWNER five (5) copies of all vendor information on items purchased and installed by CONTRACTOR. All vendor information shall be bound in a binder as approved by OWNER and submitted to OWNER prior to 44 Project # PRK-03-20 CONTRACTOR’S application for final payment. Information required shall include, but not necessarily be limited to drawings, replacement lists, vendor’s name, address, and telephone number, operating instructions, warranty, and location of service centers. SC 6.30 Replace paragraph 6.30 with the following: Indemnification: 6.30 The CONTRACTOR shall hold harmless, indemnify and defend the OWNER, their officers, employees, and agents, from any and all liability claims, losses or damage arising or alleged to arise from the performance of the work described herein, but not including the sole negligence of the OWNER. SC 11.2 Revise paragraph 11.2 as follows: Delete reference to thirty (30) days for making claim and replace with seven (7) days. SC 11.6.1 Delete “or if none can be agreed upon.” SC 11.6.2 Delete in its entirety. SC 11.9.3 Paragraph 11.9.3 of the General Conditions is hereby deleted in its entirety and the following is substituted in its place: “The united price of an item of Unit Price Work shall be subject to reevaluation and adjustment under the following conditions: 11.9.3.1 If the total cost of a particular item of Unit Price Work amounts to 15 percent or more of the Contract Price and the variation in the quantity of the particular item of Unit Price Work performed by Contractor differs by more than 25 percent from the estimated quantity of such item indicated in the Agreement; then either OWNER or CONTRACTOR may make a claim for an adjustment in the Contract Price in accordance with Article 11 if the parties are unable to agree as to the effect of any such variations in the quantity of Unity Price Work performed.” 45 Project # PRK-03-20 SC 12.1 Revise paragraph 12.1 as follows: 12.1 Delete reference to thirty (30) days for making claim and replace with seven (7) days. SC 14.2 14.2 Delete the last sentence and insert: “Retainage will be 5% of the amount paid.” SC 14.4 Amend the third sentence of paragraph 14.4 of the General Conditions to read as follows: Thirty days after…by OWNER to CONTRACTOR SC 14.5 Add the following paragraphs immediately after paragraph 14.5 of the General Conditions to read as follows: 14.5 The OWNER may retain five (5) percent of the amount of each payment until final completion and acceptance of all work covered by the CONTRACT DOCUMENTS. When the work is substantially complete (operational or beneficial occupancy), the retained amount may be further reduced below five (5) percent to only that amount necessary to assure completion. On completion and acceptance of a part of the work on which the price is stated separately in the Contract Documents, payment may be in full, including retained percentages, less authorized deductions. SC 14.7.5 Add a new paragraph immediately after paragraph 14.7.4 of the General Conditions which is to read as follows: 14.7.5 If the OWNER fails to make payment thirty (30) days after approval by the ENGINEER, in addition to other remedies available to the CONTRACTOR, there shall be added to each such payment interest at the maximum legal rate commencing on the first day after said payment is due and continuing until the payment is received by the CONTRACTOR. SC 15.2 Add the additional paragraphs after paragraph 15.2.9 of the General Conditions which is to read as follows: 46 Project # PRK-03-20 15.2.10 If, no through no act or fault of the CONTRACTOR, the WORK is stopped for a period of more than ninety (90) days by the OWNER or under an order of court or other public authority, or the ENGINEER fails to act on any request for payment within ninety (90) days after it is submitted, or the OWNER fails to pay the CONTRACTOR substantially the sum approved by the ENGINEER within thirty (30) days of its approval and presentation, then the CONTRACTOR may after ten (10) days from delivery of a WRITTEN NOTICE to the OWNER terminate the CONTRACT and recover from the OWNER payment for all WORK executed and all expenses sustained. In addition and in lieu of terminating the CONTRACT, if the OWNER has failed to act on a request for payment or if the OWNER has failed to make any payment as aforesaid, the CONTRACTOR may, upon ten (10) days written notice to the OWNER, stop the WORK until all amounts then due, in which event and upon resolution of the WORK CHANGE ORDERS shall be issued for adjusting to the CONTRACT PRICE or extending the CONTRACT TIME, or both, to compensate for the costs and delays attributable to stoppage of the WORK. 15.2.11 If the performance of all or any portion of the WORK is suspended, delayed, or interrupted as a result of a failure of the OWNER to act within the time specified in the CONTRACT DOCUMENTS, or if no time is specified, within a reasonable time, an adjustment in the CONTRACT PRICE or an extension of the CONTRACT TIME, or both, shall be made by CHANGE ORDER to compensate the CONTRACTOR for the costs and delays necessarily caused by the failure of the OWNER or ENGINEER. SC. 16 Delete Article 16 – ARBITRATION from General Conditions END OF SUPPLEMENTARY CONDITIONS ^TOP 47 Project # PRK-03-20 SPECIAL PROVISIONS BASEBALL QUAD ELECTRICAL FIELD LIGHTING INSTALLATION Project No. PRK-03-20 GENERAL INFORMATION All work associated with this project shall be performed and completed in conformance with these Contract Documents, the construction drawings pertaining to this project, the City of Rexburg Standard Drawings and Specifications, and applicable Federal, State or Local requirements or as directed by the City Engineer. PROJECT DESCRIPTION This contract involves installation of pre-purchased field lighting equipment in the Riverside Park Multipurpose Field along with providing and installing panels, conduit, wiring, and other equipment required for a complete installation. STANDARD SPECIFICATIONS AND STANDARD DRAWINGS The City of Rexburg has adopted Idaho Standards for Public Works Construction Specifications and Drawings as its (Rexburg's) Standard Specifications and Standard Drawings; and these referenced Standard Specifications and Standard Drawings shall be those governing and referenced in this Contract except as they may be amended in these Special Provisions or Project Plans. Wherever the word CITY is used in these Standards, it shall be understood to mean the City of Rexburg. Wherever the word ENGINEER or CITY ENGINEER is used, it shall be understood to mean the City Engineer of the City of Rexburg, or the Engineer the City has designated to be in charge of the project or particular part of the project work. TESTING AND STAKING Testing and Staking will be done by the City or its subcontractors. Re-testing of failing material/tests and re-staking shall be done at the expense of the contractor. The City shall be notified 24 hours prior to when testing and surveying will occur. All unscheduled surveying and testing will be the responsibility of contractor. MATERIAL SOURCES & EXCAVATION All materials such as Granular Borrow, ¾” Aggregate Base, and Topsoil shall be provided from the Contractor's own source or from a commercial source approved by the City of Rexburg. 48 Project # PRK-03-20 Compaction requirements (Sections 306.3.3 and 306.3.4) will be Type A-1 for all street locations and proposed street locations, curb and gutter, sidewalks and driveways next to streets and Type C for all landscaping and agricultural areas. Granular Borrow used for backfill shall meet the requirements of native trench backfill material, Section 306.2.2. Imported backfill shall meet the requirements of Section 801.2.1 and 801.2.2. ¾” Aggregate Base used for backfill shall meet the requirements of Section 802.2. Payment for all materials shall be included in the LUMP SUM bid items. GEOTECHNICAL REPORT The construction site for the baseball quad stadium lighting is above an old landfill site. After the Teton Dam Flood in 1976 the pit was filled with flood debris and covered with sand. Debris was found throughout including wood, burned wood, brick, metal, wire, automotive, plastic, Styrofoam and asphalt. Depth of debris varies from approximately 2-20 feet deep. A full Geotechnical report from MTI is available upon request. The contractor will be required to remove and dispose of all material that is unearthed during excavation. The cost for cleanup and disposal of all excavated material will be the responsibility of the contractor. Payment and measurement be included in the LUMP SUM bid items. 2” ELECTRICAL CONDUIT & TRENCHING An existing electrical junction box has been located close to the location for the stadium light foundation the contractor will be required provide and install new conduit from the junction box into the light pole foundation. Approximate lengths have been given on the plans. If quantity is more than the listed amount it will be considered incidental to the contract. Contractor will be required to trench to the light pole foundation and install all conduit, fittings, bend, and pole string to provide to the City a fully functional and complete system. Payment and measurement will be included in the LUMP SUM bid items. All surface restoration and repair will be included in the bid price. Contractor will be required to smooth and repair all surfaces without contaminating topsoil with subsoil. UTILITY LOCATIONS The Contractor shall request all utility companies to locate all of their utilities prior to commencement of any phase of construction that may affect said utilities. This location may be obtained for utilities within the city limits by calling 1-800-346-3972 scheduling a "locate". The Contractor shall be responsible for maintaining a record of these locations for use during construction. UTILITY SERVICE 49 Project # PRK-03-20 All utility services shall be maintained in such a manner as to cause the least inconvenience to the property owners. When utility service is disrupted as a result of the Contractor's operations, the Contractor shall provide service and shall be responsible for maintaining service to the property owner until the project is completed. ELECTRICAL SERVICE WORK INCLUDED A. Furnish all labor, materials, and equipment as required by the plans and specifications to provide a complete and workable electrical system. This specification describes the types of materials, methods, and management to be utilized. This includes the work listed in this division as well as equipment furnished under other divisions not specifically mentioned herein. B. Visit the site during the bidding period to determine existing conditions effecting electrical and other work. All costs arising from site conditions and/or preparation shall be included in the base bid. No additional charges will be allowed due to inadequate site inspection. C. Before bidding the contractor shall become familiar with the project plans, specifications and the project site. Submit requests for clarification to Owner/ENGINEER in writing prior to issuance of final addendum. After signing the contract, the Contractor shall meet the intent, purpose, and function of the contract documents. Any costs of materials, labor and equipment arising therefrom, to make each system complete and operable, is the responsibility of the contractor. CODES AND STANDARDS A. All equipment, materials, and methods of design and installation are to comply with the National Electrical Code, the basic Electrical Regulations of the State of Idaho, the Occupational Safety and Health Act (OSHA), and the requirements of any local codes at the site. Codes and standards of the following organizations may be referred to in this section and shall be considered as the minimum acceptable. A reference herein to any portion of the standard or code is not to be considered as negating any other portion of the standard or code. 1. American National Standards Institute, Inc. (ANSI) 2. Institute of Electrical & Electronic Engineers (IEEE) 3. American Society for Testing & Materials (ASTM) 4. Underwriters Laboratories, Inc. (UL) 50 Project # PRK-03-20 5. National Electric Manufacturers Association (NEMA) 6. Insulated Cable Engineers Association (IECA) 7. National Electric Code (NEC) 8. Illuminating Engineering Society (IES) 9. Instrument Society of America (ISA) B. Where the plans or these specifications require a higher degree of workmanship or quality of material than the above codes and standards imply, then these plans and specifications will prevail. EQUIPMENT, MATERIAL AND WORKMANSHIP A. All equipment and material is to be new, free from defects, of current manufacture, and listed by Underwriters Laboratories, Inc., (UL) where UL requirements apply. All materials are to be products of reputable and experienced manufacturers. Similar items in the project are to be of the same manufacturer. Use only equipment and materials of industrial quality and durability, and capable of long, reliable, trouble free service. B. The Owner reserves the right to operate defective equipment or that equipment which fails to conform to detailed specifications or does not operate satisfactorily until the defects are corrected or the equipment is repaired or replaced, without cost for depreciation, use or wear. Rejected equipment will be removed from operation only at times approved by the Owner. All equipment furnished under this section will be guaranteed for a minimum period of one (1) year from date of acceptance against defective materials, design, and workmanship in accordance with the provisions of the General Conditions. C. Provide protection for materials and equipment against loss or damage throughout the contract. Protect everything from the effect of weather prior to installation, store items to be installed in indoor location. D. Any item subject to corrosion under damp conditions and items containing insulation such as transformers and motors are to be kept in heated locations. E. Following installation, protect materials and equipment from corrosion, physical damage and effects of moisture on insulation. F. Cap all conduit runs during construction with manufactured seals. Keep openings in boxes or equipment closed. G. Layout work carefully in advance. H. Do not cut or notch any structural member or building surface without specific approval of the Engineer. Carefully carry out any cutting, channeling, chasing, or drilling of floors, walls, partitions, ceilings, pavings, or other surfaces required for the installation, support, or anchorage of conduit, raceways, or other electrical equipment. Following such work, 51 Project # PRK-03-20 restore surfaces neatly to new conditions using skilled craftsmen of the trades involved at no additional cost to the Owner. I. All work will be performed by accomplished, qualified and experienced personnel working under continuous competent supervision. PERMITS A. Obtain and pay for all permits and inspections pertinent to the electrical installation and obtain such permits from the proper governing body before any progress payment will be certified for electrical work. SITE INSPECTION A. Prior to submitting a bid, visit the project site and ascertain conditions affecting the proposed work and all existing electrical facilities. INSTALLATION A. The electrical plan drawings show general arrangements and locations for equipment conduit, outlets, etc. Unless detailed or dimensioned, exact locations of conduit, routing of cables and placement of equipment will be governed by structural conditions, physical interferences, and locations of electrical termination on equipment. Examine architectural, structural and mechanical plans and shop drawings for the various equipment in order to determine exact routing and placement of all raceways, cables, and equipment, to assure a workable installation. B. Allowances have been made in the design for the number of raceways and conductors which the Engineer considers minimum for powering and controlling all electrical equipment. If the installed equipment is of larger horsepower than shown, or if characteristics require increased power and/or conductors, the Contractor shall re-size the raceway and conductors to allow for the changed conditions and remit the information for review prior to installation. C. Be responsible for conduits, cables, and conductors necessary to meet requirements of all electrical equipment and devices. Determine final sizing of conduits and number and size of all required conductors after review of required drawings. D. Wherever possible, place conduit in the floor or wall to provide a neat and clean installation. E. All exposed conduit shall be IMC conduit. All buried conduit shall be Schedule 40 PVC with rigid metal elbows. F. Wire shall be copper THWN with AWG sizes as shown or required. LIGHTING EQUIPMENT 52 Project # PRK-03-20 Install lighting equipment and controls, in accordance with Supplier’s designs and recommendations. Construction Requirements. The Field Lighting System shall include the following: Install light poles, cross-arm assemblies, foundations, luminaires, ballasts, ballast enclosures, fuses, lighting wire harnesses, control cabinet, wireless control cabinet, key pad, and lightning protection, as described in the supplier contract documents and equipment submittals. Aim and configure the luminaires per the Supplier’s recommendations. Install new conduits and junction boxes and pull wire to each light pole through conduits. Install new wires into the existing 600 amp Schneider distribution panel. Where applicable this shall include switch rated circuit breakers for fault protection. Fuses will not be allowed. Provide proper terminations for all wiring. Support the Supplier during startup, training, and testing of lighting system. Cutting the asphalt will not be allowed. POLE BASE FOUNDATIONS Contractor shall construct pole base foundations in accordance with Supplier’s design. It is anticipated that hard pan, metal, trees, bricks, wood chips, and debris will be encountered in the foundation locations to a depth up to 20-22 feet deep. Foundations must have unsuitable material removed to the diameter and depth specified in the Supplier’s design. Provide type and strength of concrete required by Supplier’s design. Basis of Payment. Payment for accepted work will be made as a LUMP SUM. GENERAL CLEANUP The Contractor shall be responsible for the general cleanup of the project site, such as smoothing and rounding of back slopes, leveling mounds, filling voids with appropriate material and removal of all excess material. The Contractor shall pick up, load, haul and dispose of all debris left from construction. Any labor, material, or equipment used to meet the requirements of this paragraph shall be considered incidental to the project and all costs associated therewith shall be included in the contractor's lump sum price for other bid items. LAWN & LANDSCAPING REPAIR/REPLACEMENT/RECONSTRUCTION Where excavation is required through existing grassed or landscaped areas the contractor shall make every effort to disturb the area as little as possible. 53 Project # PRK-03-20 The contractor is to salvage or replace the lawn to existing conditions. In areas where lawns are disturbed the contractor is required to place a minimum of 12 inches of topsoil, level, compact and hydro seed the disturbed lawn area. The hydro seed will need to match the Baseball Quad Concessions building project hydro seed to match the species and color of new grass. Hydro seed mix design available on request. Any labor, materials or construction costs involving incidentals not mentioned (examples include but are not limited to sprinkling systems) will not be paid for separately and all costs associated therewith shall be included in the cost of other associated Contract Bid Items. DISPOSAL OF WASTE: COMPLIANCE WITH ENVIRONMENTAL LAWS Contractors shall remove, transport and properly dispose of all asphalt, debris, and waste material removed from the work site as required under the terms and conditions hereof. All such removal, transportation and disposal shall be at Contractor's sole expense and shall be accomplished in accordance with all statutes, laws, regulations and ordinances of the United States government, the State of Idaho or other agencies or local governments having jurisdiction thereof. Prior to the disposal of any hazardous chemical or regulated waste at any landfill, Contractor shall provide written proof satisfactory to the City that the operator of such landfill possesses all permits and licenses required by law in order to accept waste to be removed from the project site. Prior to acceptance of the work by the City, Contractor shall deliver to the City a certificate from the operator of any landfill wherein such waste has been delivered, stating that all such waste material has been properly disposed of in accordance with all such laws, statutes and regulations. Contractor shall hold the City harmless from all fines, penalties, costs, claims and demands of any kind, including attorneys' fees and court costs, arising from any act or omission by Contractor while removing, transporting or disposing of any hazardous substance or regulated waste at the project site. DELIVERY AND UNLOADING The delivery location for the pre-purchased lighting equipment will be at the Rexburg Baseball Quad located at 400 E. Barney Dairy Road, Rexburg, ID 83440. The Supplier will deliver the equipment and the Contractor will be required to unload the equipment. STARTUP AND TESTING Contractor will be responsible to coordinate with the Supplier and to provide support during setup, adjustment of lights, and testing. COMPLETION TIME TABLE The contractor will have forty-five (45) calendar days from the notice to proceed. Control System Summary Project Information Project #:198219 Project Name:Rexburg Baseball Quad Complex Date:01/08/20 Project Engineer:Zach Morris Sales Representative:Creighton Fuss Control System Type:LCC Communication Type:None Scan:198219D Document ID:198219P1V2-0108105816 Distribution Panel Location or ID:Baseball Total # of Distribution Panel Locations for Project:1 Design Voltage/Hertz/Phase:480/60/3 Control Voltage:120 Project Specific Notes: Materials Checklist Contractor/Customer Supplied: A dedicated control circuit must be supplied per distribution panel location. If the control voltage is NOT available, a control transformer is required. Electrical distribution panel to provide overcurrent protection for circuits HID rated or D-curve circuit breaker sized per full load amps on Circuit Summary by Zone Chart Wiring: See chart on page 2 for wiring requirements Equipment grounding conductor and splices must be insulated. (per circuit) Lightning ground protection (per pole), if not Musco supplied. Electrical conduit wireway system Entrance hubs rated NEMA 4: must be die-cast zinc, PVC, or copper-free die-cast aluminum Mounting hardware for cabinets Breaker lock-on device to prevent unauthorized power interruption to control power Anti-corrosion compound to apply to ends of wire, if necessary Equipment Listing DESCRIPTION APPROXIMATE SIZE 1.Lighting Contactor Cabinet 24 X 72 2.Lighting Contactor Cabinet 24 X 72 QTY SIZE Total Contactors 24 30 AMP Total Off/On/Auto Switches: 4 IMPORTANT NOTES 1. Please confirm that the design voltage listed above is accurate for this facility. Design voltage/phase is defined as the voltage/phase being connected and utilized at each lighting pole's electrical components enclosure disconnect. Inaccurate design voltage/phase can result in additional costs and delays. Contact your Musco sales representative to confirm this item. 2. In a 3 phase design, all 3 phases are to be run to each pole. When a 3 phase design is used Musco's single phase luminaires come pre-wired to utilize all 3 phases across the entire facility. 3. One contactor is required for each pole. When a pole has multiple circuits, one contactor is required for each circuit. All contactors are UL 100% rated for the published continuous load. All contactors are 3 pole. 4. If the lighting system will be fed from more than one distribution location, additional equipment may be required. Contact your Musco sales representative. 5. A single control circuit must be supplied per control system. 6. Size overcurrent devices using the full load amps column of the Circuit Summary By Zone chart- Minimum power factor is 0.9. NOTE: Refer to Installation Instructions for more details on equipment information and the installation requirements C 1999,2020 Musco Sports Lighting,LLC Form: T-5030-1T:\198\198219P1V2-0108105816.pdf Control System Summary Rexburg Baseball Quad Complex / 198219 - 198219D Baseball - Page 2 of 5 T:\198\198219P1V2-0108105816.pdf Control System Summary Rexburg Baseball Quad Complex / 198219 - 198219D Baseball - Page 3 of 5 T:\198\198219P1V2-0108105816.pdf CONTROL POWER CONSUMPTION 120V Single Phase VA loading of Musco Supplied Equipment INRUSH: 5880.0 SEALED: 624.0 SWITCHING SCHEDULE Field/Zone Description Zones Baseball 1 1 Baseball 2 2 Baseball 3 3 Baseball 4 4 CIRCUIT SUMMARY BY ZONE POLE CIRCUIT DESCRIPTION # OF FIXTURES # OF DRIVERS *FULL LOAD AMPS CONTACTOR SIZE (AMPS) CONTACTOR ID ZONE A1 Baseball 1 3 3 5.3 30 C1 1 A2 Baseball 1 3 3 5.3 30 C2 1 B1 Baseball 1 5 5 10.9 30 C3 1 B2 Baseball 1 5 5 10.9 30 C4 1 C1 Baseball 1 5 5 7.8 30 C5 1 C2 Baseball 1 5 5 7.8 30 C6 1 A2 Baseball 2 3 3 5.3 30 C7 2 A3 Baseball 2 3 3 5.3 30 C8 2 B2 Baseball 2 5 5 10.9 30 C9 2 B3 Baseball 2 5 5 10.9 30 C10 2 C3 Baseball 2 5 5 7.8 30 C11 2 C4 Baseball 2 5 5 7.8 30 C12 2 A3 Baseball 3 3 3 5.3 30 C13 3 A4 Baseball 3 3 3 5.3 30 C14 3 B3 Baseball 3 5 5 10.9 30 C15 3 B4 Baseball 3 5 5 10.9 30 C16 3 C5 Baseball 3 5 5 7.8 30 C17 3 C6 Baseball 3 5 5 7.8 30 C18 3 A1 Baseball 4 3 3 5.3 30 C19 4 A4 Baseball 4 3 3 5.3 30 C20 4 B1 Baseball 4 4 4 9.6 30 C21 4 B4 Baseball 4 4 4 9.6 30 C22 4 C7 Baseball 4 3 3 5.3 30 C23 4 C8 Baseball 4 3 3 5.3 30 C24 4 *Full Load Amps based on amps per driver. Control System Summary Rexburg Baseball Quad Complex / 198219 - 198219D Baseball - Page 4 of 5 T:\198\198219P1V2-0108105816.pdf PANEL SUMMARY CABINET # CONTROL MODULE LOCATION CONTACTOR ID CIRCUIT DESCRIPTION FULL LOAD AMPS DISTRIBUTION PANEL ID (BY OTHERS) CIRCUIT BREAKER POSITION (BY OTHERS) 1 ---C1 Pole A1 5.25 1 ---C2 Pole A2 5.25 1 ---C3 Pole B1 10.87 1 ---C4 Pole B2 10.87 1 ---C5 Pole C1 7.76 1 ---C6 Pole C2 7.76 1 ---C7 Pole A2 5.25 1 ---C8 Pole A3 5.25 1 ---C9 Pole B2 10.87 1 ---C10 Pole B3 10.87 1 ---C11 Pole C3 7.76 1 ---C12 Pole C4 7.76 1 ---C13 Pole A3 5.25 1 ---C14 Pole A4 5.25 2 ---C15 Pole B3 10.87 2 ---C16 Pole B4 10.87 2 ---C17 Pole C5 7.76 2 ---C18 Pole C6 7.76 2 ---C19 Pole A1 5.25 2 ---C20 Pole A4 5.25 2 ---C21 Pole B1 9.61 2 ---C22 Pole B4 9.61 2 ---C23 Pole C7 5.25 2 ---C24 Pole C8 5.25 ZONE SCHEDULE CIRCUIT DESCRIPTION ZONE SELECTOR SWITCH ZONE DESCRIPTION POLE ID CONTACTOR ID Zone 1 1 Baseball 1 A1 C1 A2 C2 B1 C3 B2 C4 C1 C5 C2 C6 Zone 2 2 Baseball 2 A2 C7 A3 C8 B2 C9 B3 C10 C3 C11 C4 C12 Zone 3 3 Baseball 3 A3 C13 A4 C14 B3 C15 B4 C16 C5 C17 CONTINUED ON NEXT PAGE Control System Summary Rexburg Baseball Quad Complex / 198219 - 198219D Baseball - Page 5 of 5 ZONE SCHEDULE CIRCUIT DESCRIPTION ZONE SELECTOR SWITCH ZONE DESCRIPTION POLE ID CONTACTOR ID Zone 3 3 Baseball 3 C6 C18 Zone 4 4 Baseball 4 A1 C19 A4 C20 B1 C21 B4 C22 C7 C23 C8 C24