Loading...
HomeMy WebLinkAboutRexburg WWTP FPS agreement Rev 1EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. Copyright © 2014: National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspe.org American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.org American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.org The copyright for this EJCDC document is owned jointly by the three sponsoring organizations listed above. The National Society of Professional Engineers is the Copyright Administrator for the EJCDC documents; please direct all inquiries regarding EJCDC copyrights to NSPE. NOTE: EJCDC publications may be purchased at www.ejcdc.org, or from any of the sponsoring organizations above. This Agreement has been prepared for use with EJCDC® C-700, Standard General Conditions of the Construction Contract, 2013 Edition. Their provisions are interrelated, and a change in one may necessitate a change in the other. For guidance on the completion and use of this Agreement, see EJCDC® E-001, Commentary on the EJCDC Engineering Services Agreements, 2013 Edition. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. TABLE OF CONTENTS Page ARTICLE 1 – SERVICES OF ENGINEER ................................................................................................................... 1 1.01 Scope .............................................................................................................................................. 1 ARTICLE 2 – OWNER’S RESPONSIBILITIES ............................................................................................................ 1 2.01 General ........................................................................................................................................... 1 ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES............................................................................................ 2 3.01 Commencement ............................................................................................................................. 2 3.02 Time for Completion ...................................................................................................................... 2 ARTICLE 4 – INVOICES AND PAYMENTS .............................................................................................................. 2 4.01 Invoices ........................................................................................................................................... 2 4.02 Payments ........................................................................................................................................ 2 ARTICLE 5 – OPINIONS OF COST .......................................................................................................................... 3 5.01 Opinions of Probable Construction Cost ....................................................................................... 3 5.02 Designing to Construction Cost Limit ............................................................................................ 3 5.03 Opinions of Total Project Costs ...................................................................................................... 3 ARTICLE 6 – GENERAL CONSIDERATIONS ............................................................................................................ 4 6.01 Standards of Performance ............................................................................................................. 4 6.02 Design Without Construction Phase Services ............................................................................... 5 6.03 Use of Documents .......................................................................................................................... 6 6.04 Electronic Transmittals ................................................................................................................... 6 6.05 Insurance ........................................................................................................................................ 7 6.06 Suspension and Termination ......................................................................................................... 8 6.07 Controlling Law ............................................................................................................................... 9 6.08 Successors, Assigns, and Beneficiaries .......................................................................................... 9 6.09 Dispute Resolution ....................................................................................................................... 10 6.10 Environmental Condition of Site .................................................................................................. 10 6.11 Indemnification and Mutual Waiver ........................................................................................... 11 6.12 Records Retention ........................................................................................................................ 12 6.13 Miscellaneous Provisions ............................................................................................................. 12 ARTICLE 7 – DEFINITIONS ................................................................................................................................... 12 7.01 Defined Terms .............................................................................................................................. 12 ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS ............................................................................................. 17 8.01 Exhibits Included: ......................................................................................................................... 17 8.02 Total Agreement: ......................................................................................................................... 17 8.03 Designated Representatives: ....................................................................................................... 17 8.04 Engineer's Certifications: ............................................................................................................. 17 EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES Owner and Engineer further agree as follows: ARTICLE 1 – SERVICES OF ENGINEER 1.01 Scope A. Engineer shall provide, or cause to be provided, the services set forth herein and in Exhibit A. ARTICLE 2 – OWNER’S RESPONSIBILITIES 2.01 General A. Owner shall have the responsibilities set forth herein and in Exhibit B. B. Owner shall pay Engineer as set forth in Article 4 and Exhibit C. C. Owner shall be responsible for all requirements and instructions that it furnishes to Engineer pursuant to this Agreement, and for the accuracy and completeness of all programs, reports, data, and other information furnished by Owner to Engineer pursuant to this Agreement. Engineer may use and rely upon such requirements, programs, instructions, reports, data, and information in performing or furnishing services under this Agreement, subject to any express limitations or reservations applicable to the furnished items. THIS IS AN AGREEMENT effective as of [December 4, 2019] (“Effective Date”) between [City of Rexburg, Idaho ] (“Owner”) and [Forsgren Associates Inc.] (“Engineer”). Owner's Project, of which Engineer's services under this Agreement are a part, is generally identified as follows: [Facilities Planning Study (FPS) for the City of Rexburg Wastewater Treatment Plant (WWTP) ] ("Project"). Other terms used in this Agreement are defined in Article 7. Engineer's services under this Agreement are generally identified as follows: [ Forsgren will provide engineering services to complete a FPS for the treatment plant facilities. The study will be completed in accordance with the State of Idaho Department of Environmental Quality (DEQ) guidance for facilities planning. The possibility exists that the Engineer will be retained for the production of design documents describing improvements, bidding assistance, construction management, and post construction services.] EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 D. Owner shall give prompt written notice to Engineer whenever Owner observes or otherwise becomes aware of: 1. any development that affects the scope or time of performance of Engineer’s services; 2. the presence at the Site of any Constituent of Concern; or 3. any relevant, material defect or nonconformance in: (a) Engineer’s services, (b) the Work, (c) the performance of any Constructor, or (d) Owner’s performance of its responsibilities under this Agreement. ARTICLE 3 – SCHEDULE FOR RENDERING SERVICES 3.01 Commencement A. Engineer is authorized to begin rendering services as of the Effective Date. 3.02 Time for Completion A. Engineer shall complete its obligations within a reasonable time. Specific periods of time for rendering services, or specific dates by which services are to be completed, are provided in Exhibit A, and are hereby agreed to be reasonable. B. If, through no fault of Engineer, such periods of time or dates are changed, or the orderly and continuous progress of Engineer’s services is impaired, or Engineer’s services are delayed or suspended, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. C. If Owner authorizes changes in the scope, extent, or character of the Project or Engineer’s services, then the time for completion of Engineer’s services, and the rates and amounts of Engineer’s compensation, shall be adjusted equitably. D. Owner shall make decisions and carry out its other responsibilities in a timely manner so as not to delay the Engineer’s performance of its services. E. If Engineer fails, through its own fault, to complete the performance required in this Agreement within the time set forth, as duly adjusted, then Owner shall be entitled, as its sole remedy, to the recovery of direct damages, if any, resulting from such failure. ARTICLE 4 – INVOICES AND PAYMENTS 4.01 Invoices A. Preparation and Submittal of Invoices: Engineer shall prepare invoices in accordance with its standard invoicing practices and the terms of Exhibit C. Engineer shall submit its invoices to Owner on a monthly basis. Invoices are due and payable within 30 days of receipt. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 4.02 Payments A. Application to Interest and Principal: Payment will be credited first to any interest owed to Engineer and then to principal. B. Failure to Pay: If Owner fails to make any payment due Engineer for services and expenses within 30 days after receipt of Engineer’s invoice, then: 1. amounts due Engineer will be increased at the rate of 1.0% per month (or the maximum rate of interest permitted by law, if less) from said thirtieth day; and 2. Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement until Owner has paid in full all amounts due for services, expenses, and other related charges. Owner waives any and all claims against Engineer for any such suspension. C. Disputed Invoices: If Owner disputes an invoice, either as to amount or entitlement, then Owner shall promptly advise Engineer in writing of the specific basis for doing so, may withhold only that portion so disputed, and must pay the undisputed portion subject to the terms of Paragraph 4.01. D. Sales or Use Taxes: If after the Effective Date any governmental entity takes a legislative action that imposes additional sales or use taxes on Engineer’s services or compensation under this Agreement, then Engineer may invoice such additional sales or use taxes for reimbursement by Owner. Owner shall reimburse Engineer for the cost of such invoiced additional sales or use taxes; such reimbursement shall be in addition to the compensation to which Engineer is entitled under the terms of Exhibit C. ARTICLE 5 – OPINIONS OF COST 5.01 Opinions of Probable Construction Cost A. Engineer’s opinions (if any) of probable Construction Cost are to be made on the basis of Engineer’s experience, qualifications, and general familiarity with the construction industry. However, because Engineer has no control over the cost of labor, materials, equipment, or services furnished by others, or over contractors’ methods of determining prices, or over competitive bidding or market conditions, Engineer cannot and does not guarantee that proposals, bids, or actual Construction Cost will not vary from opinions of probable Construction Cost prepared by Engineer. If Owner requires greater assurance as to probable Construction Cost, then Owner agrees to obtain an independent cost estimate. 5.02 Designing to Construction Cost Limit A. If a Construction Cost limit is established between Owner and Engineer, such Construction Cost limit and a statement of Engineer’s rights and responsibilities with respect thereto will be specifically set forth in Exhibit F to this Agreement. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 4 5.03 Opinions of Total Project Costs A. The services, if any, of Engineer with respect to Total Project Costs shall be limited to assisting the Owner in tabulating the various categories that comprise Total Project Costs. Engineer assumes no responsibility for the accuracy of any opinions of Total Project Costs. ARTICLE 6 – GENERAL CONSIDERATIONS 6.01 Standards of Performance A. Standard of Care: The standard of care for all professional engineering and related services performed or furnished by Engineer under this Agreement will be the care and skill ordinarily used by members of the subject profession practicing under similar circumstances at the same time and in the same locality. Engineer makes no warranties, express or implied, under this Agreement or otherwise, in connection with any services performed or furnished by Engineer. B. Technical Accuracy: Owner shall not be responsible for discovering deficiencies in the technical accuracy of Engineer’s services. Engineer shall correct deficiencies in technical accuracy without additional compensation, unless such corrective action is directly attributable to deficiencies in Owner-furnished information. C. Consultants: Engineer may retain such Consultants as Engineer deems necessary to assist in the performance or furnishing of the services, subject to reasonable, timely, and substantive objections by Owner. D. Reliance on Others: Subject to the standard of care set forth in Paragraph 6.01.A, Engineer and its Consultants may use or rely upon design elements and information ordinarily or customarily furnished by others, including, but not limited to, specialty contractors, manufacturers, suppliers, and the publishers of technical standards. E. Compliance with Laws and Regulations, and Policies and Procedures: 1. Engineer and Owner shall comply with applicable Laws and Regulations. 2. Engineer shall comply with any and all policies, procedures, and instructions of Owner that are applicable to Engineer's performance of services under this Agreement and that Owner provides to Engineer in writing, subject to the standard of care set forth in Paragraph 6.01.A, and to the extent compliance is not inconsistent with professional practice requirements. 3. This Agreement is based on Laws and Regulations and Owner-provided written policies and procedures as of the Effective Date. The following may be the basis for modifications to Owner’s responsibilities or to Engineer’s scope of services, times of performance, or compensation: a. changes after the Effective Date to Laws and Regulations; b. the receipt by Engineer after the Effective Date of Owner-provided written policies and procedures; EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 5 c. changes after the Effective Date to Owner-provided written policies or procedures. F. Engineer shall not be required to sign any document, no matter by whom requested, that would result in the Engineer having to certify, guarantee, or warrant the existence of conditions whose existence the Engineer cannot ascertain. Owner agrees not to make resolution of any dispute with the Engineer or payment of any amount due to the Engineer in any way contingent upon the Engineer signing any such document. G. The general conditions for any construction contract documents prepared hereunder are to be EJCDC® C-700 “Standard General Conditions of the Construction Contract” (2013 Edition), prepared by the Engineers Joint Contract Documents Committee, unless expressly indicated otherwise in Exhibit J or elsewhere in this Agreement. H. Engineer shall not at any time supervise, direct, control, or have authority over any Constructor’s work, nor shall Engineer have authority over or be responsible for the means, methods, techniques, sequences, or procedures of construction selected or used by any Constructor, or the safety precautions and programs incident thereto, for security or safety at the Site, nor for any failure of a Constructor to comply with Laws and Regulations applicable to that Constructor’s furnishing and performing of its work. Engineer shall not be responsible for the acts or omissions of any Constructor. I. Engineer neither guarantees the performance of any Constructor nor assumes responsibility for any Constructor’s, failure to furnish and perform the Work in accordance with the Construction Contract Documents. J. Engineer shall not be responsible for any decision made regarding the Construction Contract Documents, or any application, interpretation, clarification, or modification of the Construction Contract Documents, other than those made by Engineer or its Consultants. K. Engineer is not required to provide and does not have any responsibility for surety bonding or insurance-related advice, recommendations, counseling, or research, or enforcement of construction insurance or surety bonding requirements. L. Engineer’s services do not include providing legal advice or representation. M. Engineer’s services do not include (1) serving as a “municipal advisor” for purposes of the registration requirements of Section 975 of the Dodd-Frank Wall Street Reform and Consumer Protection Act (2010) or the municipal advisor registration rules issued by the Securities and Exchange Commission, or (2) advising Owner, or any municipal entity or other person or entity, regarding municipal financial products or the issuance of municipal securities, including advice with respect to the structure, timing, terms, or other similar matters concerning such products or issuances. N. While at the Site, Engineer, its Consultants, and their employees and representatives shall comply with the applicable requirements of Contractor's and Owner's safety programs of which Engineer has been informed in writing. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 6 6.02 Design Without Construction Phase Services A. Engineer shall be responsible only for those Construction Phase services expressly required of Engineer in Exhibit A, Paragraph A1.05. With the exception of such expressly required services, Engineer shall have no design, Shop Drawing review, or other obligations during construction, and Owner assumes all responsibility for the application and interpretation of the Construction Contract Documents, review and response to Contractor claims, Construction Contract administration, processing of Change Orders and submittals, revisions to the Construction Contract Documents during construction, construction observation and review, review of Contractor’s payment applications, and all other necessary Construction Phase administrative, engineering, and professional services. Owner waives all claims against the Engineer that may be connected in any way to Construction Phase administrative, engineering, or professional services except for those services that are expressly required of Engineer in Exhibit A. 6.03 Use of Documents A. All Documents are instruments of service, and Engineer shall retain an ownership and property interest therein (including the copyright and the right of reuse at the discretion of the Engineer) whether or not the Project is completed. B. If Engineer is required to prepare or furnish Drawings or Specifications under this Agreement, Engineer shall deliver to Owner at least one original printed record version of such Drawings and Specifications, signed and sealed according to applicable Laws and Regulations. C. Owner may make and retain copies of Documents for information and reference in connection with the use of the Documents on the Project. Engineer grants Owner a limited license to use the Documents on the Project, extensions of the Project, and for related uses of the Owner, subject to receipt by Engineer of full payment due and owing for all services relating to preparation of the Documents, and subject to the following limitations: (1) Owner acknowledges that such Documents are not intended or represented to be suitable for use on the Project unless completed by Engineer, or for use or reuse by Owner or others on extensions of the Project, on any other project, or for any other use or purpose, without written verification or adaptation by Engineer; (2) any such use or reuse, or any modification of the Documents, without written verification, completion, or adaptation by Engineer, as appropriate for the specific purpose intended, will be at Owner’s sole risk and without liability or legal exposure to Engineer or to its officers, directors, members, partners, agents, employees, and Consultants; (3) Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from all claims, damages, losses, and expenses, including attorneys’ fees, arising out of or resulting from any use, reuse, or modification of the Documents without written verification, completion, or adaptation by Engineer; and (4) such limited license to Owner shall not create any rights in third parties. D. If Engineer at Owner’s request verifies the suitability of the Documents, completes them, or adapts them for extensions of the Project or for any other purpose, then Owner shall compensate Engineer at rates or in an amount to be agreed upon by Owner and Engineer. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 7 6.04 Electronic Transmittals A. Owner and Engineer may transmit, and shall accept, Project-related correspondence, Documents, text, data, drawings, information, and graphics, in electronic media or digital format, either directly, or through access to a secure Project website, in accordance with a mutually agreeable protocol. B. If this Agreement does not establish protocols for electronic or digital transmittals, then Owner and Engineer shall jointly develop such protocols. C. When transmitting items in electronic media or digital format, the transmitting party makes no representations as to long term compatibility, usability, or readability of the items resulting from the recipient’s use of software application packages, operating systems, or computer hardware differing from those used in the drafting or transmittal of the items, or from those established in applicable transmittal protocols. 6.05 Insurance A. Engineer shall procure and maintain insurance as set forth in Exhibit G. Engineer shall cause Owner to be listed as an additional insured on any applicable general liability insurance policy carried by Engineer. B. Owner shall procure and maintain insurance as set forth in Exhibit G. Owner shall cause Engineer and its Consultants to be listed as additional insureds on any general liability policies carried by Owner, which are applicable to the Project. C. Owner shall require Contractor to purchase and maintain policies of insurance covering workers' compensation, general liability, motor vehicle damage and injuries, and other insurance necessary to protect Owner's and Engineer's interests in the Project. Owner shall require Contractor to cause Engineer and its Consultants to be listed as additional insureds with respect to such liability insurance purchased and maintained by Contractor for the Project. D. Owner and Engineer shall each deliver to the other certificates of insurance evidencing the coverages indicated in Exhibit G. Such certificates shall be furnished prior to commencement of Engineer’s services and at renewals thereafter during the life of the Agreement. E. All policies of property insurance relating to the Project, including but not limited to any builder’s risk policy, shall allow for waiver of subrogation rights and contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any insured thereunder or against Engineer or its Consultants. Owner and Engineer waive all rights against each other, Contractor, the Consultants, and the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages caused by, arising out of, or resulting from any of the perils or causes of loss covered by any builder’s risk policy and any other property insurance relating to the Project. Owner and Engineer shall take appropriate measures in other Project-related contracts to secure waivers of rights consistent with those set forth in this paragraph. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 8 F. All policies of insurance shall contain a provision or endorsement that the coverage afforded will not be canceled or reduced in limits by endorsement, and that renewal will not be refused, until at least 10 days prior written notice has been given to the primary insured. Upon receipt of such notice, the receiving party shall promptly forward a copy of the notice to the other party to this Agreement. G. At any time, Owner may request that Engineer or its Consultants, at Owner’s sole expense, provide additional insurance coverage, increased limits, or revised deductibles that are more protective than those specified in Exhibit G. If so requested by Owner, and if commercially available, Engineer shall obtain and shall require its Consultants to obtain such additional insurance coverage, different limits, or revised deductibles for such periods of time as requested by Owner, and Exhibit G will be supplemented to incorporate these requirements. 6.06 Suspension and Termination A. Suspension: 1. By Owner: Owner may suspend the Project for up to 90 days upon seven days written notice to Engineer. 2. By Engineer: Engineer may, after giving seven days written notice to Owner, suspend services under this Agreement if Owner has failed to pay Engineer for invoiced services and expenses, as set forth in Paragraph 4.02.B, or in response to the presence of Constituents of Concern at the Site, as set forth in Paragraph 6.10.D. B. Termination: The obligation to provide further services under this Agreement may be terminated: 1. For cause, a. by either party upon 30 days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. b. by Engineer: 1) upon seven days written notice if Owner demands that Engineer furnish or perform services contrary to Engineer’s responsibilities as a licensed professional; or 2) upon seven days written notice if the Engineer’s services for the Project are delayed or suspended for more than 90 days for reasons beyond Engineer’s control, or as the result of the presence at the Site of undisclosed Constituents of Concern, as set forth in Paragraph 6.10.D. 3) Engineer shall have no liability to Owner on account of such termination. c. Notwithstanding the foregoing, this Agreement will not terminate under Paragraph 6.06.B.1.a if the party receiving such notice begins, within seven days of EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 9 receipt of such notice, to correct its substantial failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt thereof; provided, however, that if and to the extent such substantial failure cannot be reasonably cured within such 30 day period, and if such party has diligently attempted to cure the same and thereafter continues diligently to cure the same, then the cure period provided for herein shall extend up to, but in no case more than, 60 days after the date of receipt of the notice. 2. For convenience, by Owner effective upon Engineer’s receipt of notice from Owner. C. Effective Date of Termination: The terminating party under Paragraph 6.06.B may set the effective date of termination at a time up to 30 days later than otherwise provided to allow Engineer to demobilize personnel and equipment from the Site, to complete tasks whose value would otherwise be lost, to prepare notes as to the status of completed and uncompleted tasks, and to assemble Project materials in orderly files. D. Payments Upon Termination: 1. In the event of any termination under Paragraph 6.06, Engineer will be entitled to invoice Owner and to receive full payment for all services performed or furnished in accordance with this Agreement and all Reimbursable Expenses incurred through the effective date of termination. Upon making such payment, Owner shall have the limited right to the use of Documents, at Owner’s sole risk, subject to the provisions of Paragraph 6.03. 2. In the event of termination by Owner for convenience or by Engineer for cause, Engineer shall be entitled, in addition to invoicing for those items identified in Paragraph 6.06.D.1, to invoice Owner and receive payment of a reasonable amount for services and expenses directly attributable to termination, both before and after the effective date of termination, such as reassignment of personnel, costs of terminating contracts with Engineer’s Consultants, and other related close-out costs, using methods and rates for Additional Services as set forth in Exhibit C. 6.07 Controlling Law A. This Agreement is to be governed by the Laws and Regulations of the state in which the Project is located. 6.08 Successors, Assigns, and Beneficiaries A. Owner and Engineer are hereby bound and the successors, executors, administrators, and legal representatives of Owner and Engineer (and to the extent permitted by Paragraph 6.08.B the assigns of Owner and Engineer) are hereby bound to the other party to this Agreement and to the successors, executors, administrators and legal representatives (and said assigns) of such other party, in respect of all covenants, agreements, and obligations of this Agreement. B. Neither Owner nor Engineer may assign, sublet, or transfer any rights under or interest (including, but without limitation, money that is due or may become due) in this EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 10 Agreement without the written consent of the other party, except to the extent that any assignment, subletting, or transfer is mandated by law. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. C. Unless expressly provided otherwise in this Agreement: 1. Nothing in this Agreement shall be construed to create, impose, or give rise to any duty owed by Owner or Engineer to any Constructor, other third-party individual or entity, or to any surety for or employee of any of them. 2. All duties and responsibilities undertaken pursuant to this Agreement will be for the sole and exclusive benefit of Owner and Engineer and not for the benefit of any other party. 3. Owner agrees that the substance of the provisions of this Paragraph 6.08.C shall appear in the Construction Contract Documents. 6.09 Dispute Resolution A. Owner and Engineer agree to negotiate all disputes between them in good faith for a period of 30 days from the date of notice prior to invoking the procedures of Exhibit H or other provisions of this Agreement, or exercising their rights at law. B. If the parties fail to resolve a dispute through negotiation under Paragraph 6.09.A, then either or both may invoke the procedures of Exhibit H. If Exhibit H is not included, or if no dispute resolution method is specified in Exhibit H, then the parties may exercise their rights at law. 6.10 Environmental Condition of Site A. Owner represents to Engineer that as of the Effective Date to the best of Owner’s knowledge no Constituents of Concern, other than those disclosed in writing to Engineer, exist at or adjacent to the Site. B. If Engineer encounters or learns of an undisclosed Constituent of Concern at the Site, then Engineer shall notify (1) Owner and (2) appropriate governmental officials if Engineer reasonably concludes that doing so is required by applicable Laws or Regulations. C. It is acknowledged by both parties that Engineer’s scope of services does not include any services related to unknown or undisclosed Constituents of Concern. If Engineer or any other party encounters, uncovers, or reveals an undisclosed Constituent of Concern, then Owner shall promptly determine whether to retain a qualified expert to evaluate such condition or take any necessary corrective action. D. If investigative or remedial action, or other professional services, are necessary with respect to undisclosed Constituents of Concern, or if investigative or remedial action beyond that reasonably contemplated is needed to address a disclosed or known Constituent of Concern, then Engineer may, at its option and without liability for consequential or any other damages, suspend performance of services on the portion of the Project affected thereby until such portion of the Project is no longer affected. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 11 E. If the presence at the Site of undisclosed Constituents of Concern adversely affects the performance of Engineer’s services under this Agreement, then the Engineer shall have the option of (1) accepting an equitable adjustment in its compensation or in the time of completion, or both; or (2) terminating this Agreement for cause on seven days notice. F. Owner acknowledges that Engineer is performing professional services for Owner and that Engineer is not and shall not be required to become an "owner," “arranger,” “operator,” “generator,” or “transporter” of hazardous substances, as defined in the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA), as amended, which are or may be encountered at or near the Site in connection with Engineer’s activities under this Agreement. 6.11 Indemnification and Mutual Waiver A. Indemnification by Engineer: To the fullest extent permitted by Laws and Regulations, Engineer shall indemnify and hold harmless Owner, and Owner’s officers, directors, members, partners, agents, consultants, and employees, from losses, damages, and judgments (including reasonable consultants’ and attorneys’ fees and expenses) arising from third-party claims or actions relating to the Project, provided that any such claim, action, loss, damages, or judgment is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Engineer or Engineer’s officers, directors, members, partners, agents, employees, or Consultants. This indemnification provision is subject to and limited by the provisions, if any, agreed to by Owner and Engineer in Exhibit I, “Limitations of Liability." B. Indemnification by Owner: Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants as required by Laws and Regulations and to the extent (if any) required in Exhibit I, “Limitations of Liability.” C. Environmental Indemnification: To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from all claims, costs, losses, damages, actions, and judgments (including reasonable consultants’ and attorneys fees and expenses) caused by, arising out of, relating to, or resulting from a Constituent of Concern at, on, or under the Site, provided that (1) any such claim, cost, loss, damages, action, or judgment is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, and (2) nothing in this paragraph shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence or willful misconduct. D. No Defense Obligation: The indemnification commitments in this Agreement do not include a defense obligation by the indemnitor unless such obligation is expressly stated. E. Percentage Share of Negligence: To the fullest extent permitted by Laws and Regulations, a party’s total liability to the other party and anyone claiming by, through, or under the EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 12 other party for any cost, loss, or damages caused in part by the negligence of the party and in part by the negligence of the other party or any other negligent entity or individual, shall not exceed the percentage share that the party’s negligence bears to the total negligence of Owner, Engineer, and all other negligent entities and individuals. F. Mutual Waiver: To the fullest extent permitted by Laws and Regulations, Owner and Engineer waive against each other, and the other’s employees, officers, directors, members, agents, insurers, partners, and consultants, any and all claims for or entitlement to special, incidental, indirect, or consequential damages arising out of, resulting from, or in any way related to this Agreement or the Project, from any cause or causes. 6.12 Records Retention A. Engineer shall maintain on file in legible form, for a period of five years following completion or termination of its services, all Documents, records (including cost records), and design calculations related to Engineer’s services or pertinent to Engineer’s performance under this Agreement. Upon Owner’s request, Engineer shall provide a copy of any such item to Owner at cost. 6.13 Miscellaneous Provisions A. Notices: Any notice required under this Agreement will be in writing, addressed to the appropriate party at its address on the signature page and given personally, by registered or certified mail postage prepaid, or by a commercial courier service. All notices shall be effective upon the date of receipt. B. Survival: All express representations, waivers, indemnifications, and limitations of liability included in this Agreement will survive its completion or termination for any reason. C. Severability: Any provision or part of the Agreement held to be void or unenforceable under any Laws or Regulations shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Engineer, which agree that the Agreement shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. D. Waiver: A party’s non-enforcement of any provision shall not constitute a waiver of that provision, nor shall it affect the enforceability of that provision or of the remainder of this Agreement. E. Accrual of Claims: To the fullest extent permitted by Laws and Regulations, all causes of action arising under this Agreement shall be deemed to have accrued, and all statutory periods of limitation shall commence, no later than the date of Substantial Completion. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 13 ARTICLE 7 – DEFINITIONS 7.01 Defined Terms A. Wherever used in this Agreement (including the Exhibits hereto) terms (including the singular and plural forms) printed with initial capital letters have the meanings indicated in the text above, in the exhibits, or in the following definitions: 1. Addenda—Written or graphic instruments issued prior to the opening of bids which clarify, correct, or change the bidding requirements or the proposed Construction Contract Documents. 2. Additional Services—The services to be performed for or furnished to Owner by Engineer in accordance with Part 2 of Exhibit A of this Agreement. 3. Agreement—This written contract for professional services between Owner and Engineer, including all exhibits identified in Paragraph 8.01 and any duly executed amendments. 4. Application for Payment—The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Construction Contract. 5. Basic Services—The services to be performed for or furnished to Owner by Engineer in accordance with Part 1 of Exhibit A of this Agreement. 6. Change Order—A document which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Construction Contract Price or the Construction Contract Times, or other revision to the Construction Contract, issued on or after the effective date of the Construction Contract. 7. Change Proposal—A written request by Contractor, duly submitted in compliance with the procedural requirements set forth in the Construction Contract, seeking an adjustment in Construction Contract Price or Construction Contract Times, or both; contesting an initial decision by Engineer concerning the requirements of the Construction Contract Documents or the acceptability of Work under the Construction Contract Documents; challenging a set-off against payments due; or seeking other relief with respect to the terms of the Construction Contract. 8. Constituent of Concern—Asbestos, petroleum, radioactive material, polychlorinated biphenyls (PCBs), hazardous waste, and any substance, product, waste, or other material of any nature whatsoever that is or becomes listed, regulated, or addressed pursuant to (a) the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. §§9601 et seq. (“CERCLA”); (b) the Hazardous Materials Transportation Act, 49 U.S.C. §§5501 et seq.; (c) the Resource Conservation and Recovery Act, 42 U.S.C. §§6901 et seq. (“RCRA”); (d) the Toxic Substances Control Act, 15 U.S.C. §§2601 et seq.; (e) the Clean Water Act, 33 U.S.C. §§1251 et seq.; (f) the Clean Air Act, 42 U.S.C. §§7401 et seq.; or (g) any other federal, State, or local statute, law, rule, regulation, ordinance, EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 14 resolution, code, order, or decree regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, or material. 9. Construction Contract—The entire and integrated written contract between the Owner and Contractor concerning the Work. 10. Construction Contract Documents—Those items designated as “Contract Documents” in the Construction Contract, and which together comprise the Construction Contract. 11. Construction Contract Price—The money that Owner has agreed to pay Contractor for completion of the Work in accordance with the Construction Contract Documents. 12. Construction Contract Times—The number of days or the dates by which Contractor shall: (a) achieve milestones, if any, in the Construction Contract; (b) achieve Substantial Completion; and (c) complete the Work. 13. Construction Cost—The cost to Owner of the construction of those portions of the entire Project designed or specified by or for Engineer under this Agreement, including construction labor, services, materials, equipment, insurance, and bonding costs, and allowances for contingencies. Construction Cost does not include costs of services of Engineer or other design professionals and consultants; cost of land or rights-of-way, or compensation for damages to property; Owner’s costs for legal, accounting, insurance counseling, or auditing services; interest or financing charges incurred in connection with the Project; or the cost of other services to be provided by others to Owner. Construction Cost is one of the items comprising Total Project Costs. 14. Constructor—Any person or entity (not including the Engineer, its employees, agents, representatives, and Consultants), performing or supporting construction activities relating to the Project, including but not limited to Contractors, Subcontractors, Suppliers, Owner’s work forces, utility companies, other contractors, construction managers, testing firms, shippers, and truckers, and the employees, agents, and representatives of any or all of them. 15. Consultants—Individuals or entities having a contract with Engineer to furnish services with respect to this Project as Engineer’s independent professional associates and consultants; subcontractors; or vendors. 16. Contractor—The entity or individual with which Owner enters into a Construction Contract. 17. Documents—Data, reports, Drawings, Specifications, Record Drawings, building information models, civil integrated management models, and other deliverables, whether in printed or electronic format, provided or furnished in appropriate phases by Engineer to Owner pursuant to this Agreement. 18. Drawings—That part of the Construction Contract Documents that graphically shows the scope, extent, and character of the Work to be performed by Contractor. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 15 19. Effective Date—The date indicated in this Agreement on which it becomes effective, but if no such date is indicated, the date on which this Agreement is signed and delivered by the last of the parties to sign and deliver. 20. Engineer—The individual or entity named as such in this Agreement. 21. Field Order—A written order issued by Engineer which requires minor changes in the Work but does not change the Construction Contract Price or the Construction Contract Times. 22. Laws and Regulations; Laws or Regulations—Any and all applicable laws, statutes, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 23. Owner—The individual or entity named as such in this Agreement and for which Engineer's services are to be performed. Unless indicated otherwise, this is the same individual or entity that will enter into any Construction Contracts concerning the Project. 24. Project—The total undertaking to be accomplished for Owner by engineers, contractors, and others, including planning, study, design, construction, testing, commissioning, and start-up, and of which the services to be performed or furnished by Engineer under this Agreement are a part. 25. Record Drawings—Drawings depicting the completed Project, or a specific portion of the completed Project, prepared by Engineer as an Additional Service and based on Contractor's record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications, as delivered to Engineer and annotated by Contractor to show changes made during construction. 26. Reimbursable Expenses—The expenses incurred directly by Engineer in connection with the performing or furnishing of Basic Services and Additional Services for the Project. 27. Resident Project Representative—The authorized representative of Engineer assigned to assist Engineer at the Site during the Construction Phase. As used herein, the term Resident Project Representative or "RPR" includes any assistants or field staff of Resident Project Representative. The duties and responsibilities of the Resident Project Representative, if any, are as set forth in Exhibit D. 28. Samples—Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and that establish the standards by which such portion of the Work will be judged. 29. Shop Drawings—All drawings, diagrams, illustrations, schedules, and other data or information that are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. Shop Drawings, whether approved or not, are not Drawings and are not Construction Contract Documents. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 16 30. Site—Lands or areas to be indicated in the Construction Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements, and such other lands furnished by Owner which are designated for the use of Contractor. 31. Specifications—The part of the Construction Contract Documents that consists of written requirements for materials, equipment, systems, standards, and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable to the Work. 32. Subcontractor—An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work. 33. Substantial Completion—The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Construction Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms “substantially complete” and “substantially completed” as applied to all or part of the Work refer to Substantial Completion thereof. 34. Supplier—A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or a Subcontractor. 35. Total Project Costs—The total cost of planning, studying, designing, constructing, testing, commissioning, and start-up of the Project, including Construction Cost and all other Project labor, services, materials, equipment, insurance, and bonding costs, allowances for contingencies, and the total costs of services of Engineer or other design professionals and consultants, together with such other Project-related costs that Owner furnishes for inclusion, including but not limited to cost of land, rights-of-way, compensation for damages to properties, Owner’s costs for legal, accounting, insurance counseling, and auditing services, interest and financing charges incurred in connection with the Project, and the cost of other services to be provided by others to Owner. 36. Work—The entire construction or the various separately identifiable parts thereof required to be provided under the Construction Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction; furnishing, installing, and incorporating all materials and equipment into such construction; and may include related services such as testing, start-up, and commissioning, all as required by the Construction Contract Documents. 37. Work Change Directive—A written directive to Contractor issued on or after the effective date of the Construction Contract, signed by Owner and recommended by Engineer, ordering an addition, deletion, or revision in the Work. B. Day: EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 17 1. The word “day” means a calendar day of 24 hours measured from midnight to the next midnight. ARTICLE 8 – EXHIBITS AND SPECIAL PROVISIONS 8.01 Exhibits Included: A. Exhibit A, Engineer’s Services. B. Exhibit B, Owner’s Responsibilities. C. Exhibit C, Payments to Engineer for Services and Reimbursable Expenses. D. Exhibit D, Duties, Responsibilities and Limitations of Authority of Resident Project Representative. -NOT USED E. Exhibit E, Notice of Acceptability of Work. -NOT USED F. Exhibit F, Construction Cost Limit. -NOT USED G. Exhibit G, Insurance. -NOT USED H. Exhibit H, Dispute Resolution. I. Exhibit I, Limitations of Liability. J. Exhibit J, Special Provisions. -NOT USED K. Exhibit K, Amendment to Owner-Engineer Agreement. 8.02 Total Agreement A. This Agreement, (together with the exhibits included above) constitutes the entire agreement between Owner and Engineer and supersedes all prior written or oral understandings. This Agreement may only be amended, supplemented, modified, or canceled by a written instrument duly executed by both parties. Amendments should be based whenever possible on the format of Exhibit K to this Agreement. 8.03 Designated Representatives A. With the execution of this Agreement, Engineer and Owner shall designate specific individuals to act as Engineer’s and Owner’s representatives with respect to the services to be performed or furnished by Engineer and responsibilities of Owner under this Agreement. Such an individual shall have authority to transmit instructions, receive information, and render decisions relative to this Agreement on behalf of the respective party whom the individual represents. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 18 8.04 Engineer's Certifications A. Engineer certifies that it has not engaged in corrupt, fraudulent, or coercive practices in competing for or in executing the Agreement. For the purposes of this Paragraph 8.04: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the selection process or in the Agreement execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the selection process or the execution of the Agreement to the detriment of Owner, or (b) to deprive Owner of the benefits of free and open competition; 3. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the selection process or affect the execution of the Agreement. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 19 IN WITNESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is indicated on page 1. Owner: [City of Rexburg, Idaho] Engineer: [Forsgren Associates, Inc.] By: [ ] By: [ ] Print name: [ ] Print name: [Kevin Harris] Title: [ ] Title: [Division Manager] Date Signed: [ ] Date Signed: [November 20, 2019] Engineer License or Firm's Certificate No. (if required): [11364 ] State of: [Idaho] Address for Owner’s receipt of notices: Address for Engineer’s receipt of notices: [ ] [350 North 2nd East Rexburg, Idaho 83440] Designated Representative (Paragraph 8.03.A): Designated Representative (Paragraph 8.03.A): [ ] [Kevin Harris] Title: [ ] Title: [Division Manager] Phone Number: [ ] Phone Number: [208-356-9201] E-Mail Address: [ ] E-Mail Address: [kharris@forsgren.com] Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT A, consisting of [8] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Engineer’s Services Article 1 of the Agreement is supplemented to include the following agreement of the parties. Engineer shall provide Basic and Additional Services as set forth below. PART 1 – BASIC SERVICES A1.01 Study and Report Phase A. Engineer shall: 1. Consult with Owner to define and clarify Owner’s requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility, and expandability, and any budgetary limitations, and identify available data, information, reports, facilities plans, and site evaluations. a. If Owner has already identified one or more potential solutions to meet its Project requirements, then proceed with the study and evaluation of such potential solutions: [None] b. If Owner has not identified specific potential solutions for study and evaluation, then assist Owner in determining whether Owner’s requirements, and available data, reports, plans, and evaluations, point to a single potential solution for Engineer’s study and evaluation, or are such that it will be necessary for Engineer to identify, study, and evaluate multiple potential solutions. c. If it is necessary for Engineer to identify, study, and evaluate multiple potential solutions, then identify [2] alternative solutions potentially available to Owner, unless Owner and Engineer mutually agree that some other specific number of alternatives should be identified, studied, and evaluated. 2. Identify potential solution(s) to meet Owner’s Project requirements, as needed. 3. Study and evaluate the potential solution(s) to meet Owner’s Project requirements. 4. Visit the Site, or potential Project sites, to review existing conditions and facilities, unless such visits are not necessary or applicable to meeting the objectives of the Study and Report Phase. 5. Advise Owner of any need for Owner to obtain, furnish, or otherwise make available to Engineer additional Project-related data and information, for Engineer’s use in the study and evaluation of potential solution(s) to Owner’s Project requirements, and preparation of a related report. Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 6. After consultation with Owner, recommend to Owner the solution(s) which in Engineer’s judgment meet Owner’s requirements for the Project. 7. Identify, consult with, and analyze requirements of governmental authorities having jurisdiction to approve the portions of the Project to be designed or specified by Engineer, including but not limited to mitigating measures identified in an environmental assessment for the Project. 8. Prepare a report (the “Report”) which will, as appropriate, contain schematic layouts, sketches, and conceptual design criteria with appropriate exhibits to indicate the agreed-to requirements, considerations involved, and Engineer’s recommended solution(s). For each recommended solution Engineer will provide the following, which will be separately itemized: opinion of probable Construction Cost; proposed allowances for contingencies; the estimated total costs of design, professional, and related services to be provided by Engineer and its Consultants; and, on the basis of information furnished by Owner, a tabulation of other items and services included within the definition of Total Project Costs. 9. Advise Owner of any need for Owner to provide data or services of the types described in Exhibit B, for use in Project design, or in preparation for Contractor selection and construction. 10. When mutually agreed, assist Owner in evaluating the possible use of building information modeling; civil integrated management; geotechnical baselining of subsurface site conditions; innovative design, contracting, or procurement strategies; or other strategies, technologies, or techniques for assisting in the design, construction, and operation of Owner’s facilities. The subject matter of this paragraph shall be referred to in Exhibit A and B as “Project Strategies, Technologies, and Techniques.” 11. If requested to do so by Owner, assist Owner in identifying opportunities for enhancing the sustainability of the Project, and pursuant to Owner’s instructions plan for the inclusion of sustainable features in the design. 12. Use ASCE 38, “Standard Guideline for the Collection and Depiction of Existing Subsurface Utility Data” as a means to advise the Owner on a recommended scope of work and procedure for the identification and mapping of existing utilities. 13. Develop a scope of work and survey limits for any topographic and other surveys necessary for design. 14. Perform or provide the following other Study and Report Phase tasks or deliverables: The specific tasks of the project are as described below. TASK 1 – PROJECT MANAGEMENT 1.1 Project Coordination/Invoicing 1.2 Project Meetings as needed (prepare agendas and document minutes) 1.3 Progress Reports TASK 2 – WASTEWATER TREATMENT PLANT FPS 2.1 Review Planning Information Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 2.1.1 Define project need, and review planning area 2.1.2 Review demographics population projections that have been previously determined for the WW Collection System FPS prepared by others 2.1.3 Review and update wastewater flows, current and projected 2.1.3.1 The flow analysis will include a breakdown of the total occupied capacity - split amongst the contributors (Rexburg, Sugar City, Teton, significant industrial users, and obligated) with an available balance. 2.1.3.2 Review and evaluate the effect of septage dumpers at the plant. 2.1.3.3 Review if any dischargers should be listed as Significant Industrial Users (SIU’s) 2.1.4 Review and update wastewater quality data (additional sampling and testing will be performed by the City, including any rental of equipment) 2.1.5 Evaluate new discharge permit 2.1.5.1 Determine effluent limits 2.1.6 Define design criteria for future conditions 2.2 Evaluate Existing Treatment System 2.2.1 Review existing performance data 2.2.2 Review capacity of each process (hydraulic and biological loading) 2.2.2.1 Review of Idaho DEQ redundancy requirements 2.2.3 Identify data gaps and recommend testing locations and frequencies (additional sampling and testing will be performed by the City, including any rental of equipment) 2.2.4 Review current Idaho DEQ rules applicable to plant and identify areas of non-compliance 2.2.5 Visit site to review condition of treatment system components 2.2.6 Evaluate and recommend effluent limits for SIU’s 2.3 Develop Alternatives for Treatment System Upgrades based on current and future flow conditions with the forthcoming NPDES permit requirements. Alternative to be developed include: 2.3.1 No action alternative 2.3.2 Headworks upgrades 2.3.3 Secondary treatment upgrades 2.3.4 Disinfection upgrades 2.3.5 Biosolids Treatment upgrades 2.3.6 Other upgrades as determined (i.e. primary treatment upgrades) 2.4 Evaluate Alternatives and Select Preferred Alternative 2.4.1 Evaluate and compare alternatives for non-financial factors, including complexity, reliability, energy requirements, implementability, operations, environmental evaluation, and views of the public and concerned interest groups. 2.4.2 Evaluate and compare alternatives for financial factors, including monetary costs including life cycle costs, reserve capacity, demonstration of financial capability, and capital financing plan. 2.4.3 Select preferred alternative for implementation. The preferred alternative will include a list of corrective actions for each of the system deficiencies Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 4 identified. This list will be organized into a capital project implementation plan. If administrative or system maintenance projects are identified, these items will also be organized into an implementation schedule. 2.5 Develop Preferred Alternative Implementation Plan, including: 2.5.1 Costs and funding alternatives 2.5.2 Schedule 2.5.3 Financial feasibility review that includes a recommendation for user rates 2.5.4 Implementation phasing and schedule that includes the estimated year, population, and flow when the improvement will be needed 2.6 Provide Draft Report, Conduct Review Meeting, and Incorporate Comments 2.7 Provide Final Report (4 paper copies plus a searchable pdf file) 2.8 Coordinate DEQ Review 15. Furnish [2] review copies of the Report and any other Study and Report Phase deliverables to Owner within [208 (June 29, 2020)] days of the Effective Date and review it with Owner. Within [30] days of receipt, Owner shall submit to Engineer any comments regarding the furnished items. 16. Revise the Report and any other Study and Report Phase deliverables in response to Owner’s comments, as appropriate, and furnish [4] copies of the revised Report and any other Study and Report Phase deliverables to the Owner within [14] days of receipt of Owner’s comments. B. Engineer’s services under the Study and Report Phase will be considered complete on the date when Engineer has delivered to Owner the revised Report and any other Study and Report Phase deliverables. PART 2 – ADDITIONAL SERVICES A2.01 Additional Services Requiring Owner’s Written Authorization A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Exhibit C. 1. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project. 2. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others. Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 5 3. Services resulting from significant changes in the scope, extent, or character of the portions of the Project designed or specified by Engineer, or the Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control. 4. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Paragraph A1.01.A.1 and 2. 5. Services required as a result of Owner’s providing incomplete or incorrect Project information to Engineer. 6. Providing renderings or models for Owner’s use, including services in support of building information modeling or civil integrated management. 7. Undertaking investigations and studies including, but not limited to: a. detailed consideration of operations, maintenance, and overhead expenses; b. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities; c. preparation of appraisals; d. evaluating processes available for licensing, and assisting Owner in obtaining process licensing; e. detailed quantity surveys of materials, equipment, and labor; and f. audits or inventories required in connection with construction performed or furnished by Owner. 8. Furnishing services of Consultants for other than Basic Services. 9. Providing data or services of the types described in Exhibit B, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same. 10. Providing the following services: a. Review environmental information for preferred alternative (such as environmental information, historical and archaeological sites, floodplains and wetlands, agricultural lands, wild and scenic rivers, fish and wildlife protection, air quality, water quality and quantity) to determine if further detailed environmental review is required. It is anticipated to complete the necessary effort for a determination of “Categorical Exclusion.” Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 6 b. In the event that a determination of “Categorical Exclusion” is inadequate for the Preferred Alternative, and either a “Finding of No Significant Impact” (FONSI) or an Environmental Information Document (EID) is required. The effort to complete the necessary document will be negotiated at that time. c. WWTP modelling 11. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Part 1 of Exhibit A). 12. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructibility review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes. 13. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents) or Construction Contract Documents for alternate bids or cost estimates requested by Owner for the Work or a portion thereof. 14. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services, except when such assistance is required to complete services required by Paragraph 5.02.A and Exhibit F. 15. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all Addenda and any amendments negotiated by Owner and Contractor. 16. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date. 17. Preparing Record Drawings, and furnishing such Record Drawings to Owner. 18. Supplementing Record Drawings with information regarding the completed Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources. 19. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed. 20. Preparation of operation, maintenance, and staffing manuals. 21. Protracted or extensive assistance in refining and adjusting of Project equipment and systems (such as initial startup, testing, and balancing). 22. Assistance to Owner in training Owner’s staff to operate and maintain Project equipment and systems. Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 7 23. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Project equipment and systems, and (b) related recordkeeping. 24. Preparing to serve or serving as a consultant or witness for Owner in any litigation, arbitration, lien or bond claim, or other legal or administrative proceeding involving the Project. 25. Overtime work requiring higher than regular rates. 26. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Paragraph A1.05.A.8; any type of property surveys or related engineering services needed for the transfer of interests in real property; and providing other special field surveys. 27. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner. 28. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services). 29. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. A2.02 Additional Services Not Requiring Owner’s Written Authorization A. Engineer shall advise Owner that Engineer is commencing to perform or furnish the Additional Services of the types listed below. For such Additional Services, Engineer need not request or obtain specific advance written authorization from Owner. Engineer shall cease performing or furnishing such Additional Services upon receipt of written notice to cease from Owner. 1. Services in connection with Work Change Directives and Change Orders to reflect changes requested by Owner. 2. Services in making revisions to Drawings and Specifications occasioned by the acceptance of substitute materials or equipment other than “or equal” items; services after the award of the Construction Contract in evaluating and determining the acceptability of a proposed "or equal" or substitution which is found to be inappropriate for the Project; evaluation and determination of an excessive number of proposed "or equals" or substitutions, whether proposed before or after award of the Construction Contract. 3. Services resulting from significant delays, changes, or price increases occurring as a direct or indirect result of materials, equipment, or energy shortages. 4. Additional or extended services arising from (a) the presence at the Site of any Constituent of Concern or items of historical or cultural significance, (b) emergencies or acts of God endangering the Work, (c) damage to the Work by fire or other causes Exhibit A – Engineer’s Services EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 8 during construction, (d) a significant amount of defective, neglected, or delayed Work, (e) acceleration of the progress schedule involving services beyond normal working hours, or (f) default by Contractor. 5. Services (other than Basic Services during the Post-Construction Phase) in connection with any partial utilization of the Work by Owner prior to Substantial Completion. 6. Evaluating unreasonable or frivolous requests for interpretation or information (RFIs), Change Proposals, or other demands from Contractor or others in connection with the Work, or an excessive number of RFIs, Change Proposals, or demands. 7. Reviewing a Shop Drawing or other Contractor submittal more than three times, as a result of repeated inadequate submissions by Contractor. 8. While at the Site, compliance by Engineer and its staff with those terms of Owner's or Contractor's safety program provided to Engineer subsequent to the Effective Date that exceed those normally required of engineering personnel by federal, State, or local safety authorities for similar construction sites. Exhibit B – Owner's Responsibilities EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT B, consisting of [3] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Owner’s Responsibilities Article 2 of the Agreement is supplemented to include the following agreement of the parties. B2.01 In addition to other responsibilities of Owner as set forth in this Agreement, Owner shall at its expense: A. Provide Engineer with all criteria and full information as to Owner’s requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility, and expandability, and any budgetary limitations. B. Give instructions to Engineer regarding Owner’s procurement of construction services (including instructions regarding advertisements for bids, instructions to bidders, and requests for proposals, as applicable), Owner’s construction contract practices and requirements, insurance and bonding requirements, electronic transmittals during construction, and other information necessary for the finalization of Owner’s bidding-related documents (or requests for proposals or other construction procurement documents), and Construction Contract Documents. Furnish copies (or give specific directions requesting Engineer to use copies already in Engineer’s possession) of all design and construction standards, Owner’s standard forms, general conditions (if other than EJCDC® C-700, Standard General Conditions of the Construction Contract, 2013 Edition), supplementary conditions, text, and related documents and content for Engineer to include in the draft bidding-related documents (or requests for proposals or other construction procurement documents), and draft Construction Contract Documents, when applicable. Owner shall have responsibility for the final content of (1) such bidding-related documents (or requests for proposals or other construction procurement documents), and (2) those portions of any Construction Contract other than the design (as set forth in the Drawings, Specifications, or otherwise), and other engineering or technical matters; and Owner shall seek the advice of Owner’s legal counsel, risk managers, and insurance advisors with respect to the drafting and content of such documents. C. Furnish to Engineer any other available information pertinent to the Project including reports and data relative to previous designs, construction, or investigation at or adjacent to the Site. D. Following Engineer’s assessment of initially-available Project information and data and upon Engineer’s request, obtain, furnish, or otherwise make available (if necessary through title searches, or retention of specialists or consultants) such additional Project-related information and data as is reasonably required to enable Engineer to complete its Basic and Additional Services. Such additional information or data would generally include the following: 1. Property descriptions. 2. Zoning, deed, and other land use restrictions. Exhibit B – Owner's Responsibilities EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 3. Utility and topographic mapping and surveys. 4. Property, boundary, easement, right-of-way, and other special surveys or data, including establishing relevant reference points. 5. Explorations and tests of subsurface conditions at or adjacent to the Site; geotechnical reports and investigations; drawings of physical conditions relating to existing surface or subsurface structures at the Site; hydrographic surveys, laboratory tests and inspections of samples, materials, and equipment; with appropriate professional interpretation of such information or data. 6. Environmental assessments, audits, investigations, and impact statements, and other relevant environmental, historical, or cultural studies relevant to the Project, the Site, and adjacent areas. 7. Data or consultations as required for the Project but not otherwise identified in this Agreement. E. Arrange for safe access to and make all provisions for Engineer to enter upon public and private property as required for Engineer to perform services under the Agreement. F. Recognizing and acknowledging that Engineer's services and expertise do not include the following services, provide, as required for the Project: 1. Accounting, bond and financial advisory (including, if applicable, “municipal advisor” services as described in Section 975 of the Dodd-Frank Wall Street Reform and Consumer Protection Act (2010) and the municipal advisor registration rules issued by the Securities and Exchange Commission), independent cost estimating, and insurance counseling services. 2. Legal services with regard to issues pertaining to the Project as Owner requires, Contractor raises, or Engineer reasonably requests. 3. Such auditing services as Owner requires to ascertain how or for what purpose Contractor has used the money paid. G. Provide the services of an independent testing laboratory to perform all inspections, tests, and approvals of samples, materials, and equipment required by the Construction Contract Documents (other than those required to be furnished or arranged by Contractor), or to evaluate the performance of materials, equipment, and facilities of Owner, prior to their incorporation into the Work with appropriate professional interpretation thereof. Provide Engineer with the findings and reports generated by testing laboratories, including findings and reports obtained from or through Contractor. H. Provide reviews, approvals, and permits from all governmental authorities having jurisdiction to approve all phases of the Project designed or specified by Engineer and such reviews, approvals, and consents from others as may be necessary for completion of each phase of the Project. Exhibit B – Owner's Responsibilities EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 3 I. Advise Engineer of the identity and scope of services of any independent consultants employed by Owner to perform or furnish services in regard to the Project, including, but not limited to, cost estimating, project peer review, value engineering, and constructibility review. J. If Owner designates a construction manager or an individual or entity other than, or in addition to, Engineer to represent Owner at the Site, define and set forth as an attachment to this Exhibit B the duties, responsibilities, and limitations of authority of such other party and the relation thereof to the duties, responsibilities, and authority of Engineer. K. If more than one prime contract is to be awarded for the Work designed or specified by Engineer, then designate a person or entity to have authority and responsibility for coordinating the activities among the various prime Contractors, and define and set forth the duties, responsibilities, and limitations of authority of such individual or entity and the relation thereof to the duties, responsibilities, and authority of Engineer as an attachment to this Exhibit B that is to be mutually agreed upon and made a part of this Agreement before such services begin. L. Inform Engineer in writing of any specific requirements of safety or security programs that are applicable to Engineer, as a visitor to the Site. M. Examine all alternative solutions, studies, reports, sketches, Drawings, Specifications, proposals, and other documents presented by Engineer (including obtaining advice of an attorney, risk manager, insurance counselor, financial/municipal advisor, and other advisors or consultants as Owner deems appropriate with respect to such examination) and render in writing timely decisions pertaining thereto. N. Inform Engineer regarding any need for assistance in evaluating the possible use of Project Strategies, Technologies, and Techniques, as defined in Exhibit A. O. Advise Engineer as to whether Engineer’s assistance is requested in identifying opportunities for enhancing the sustainability of the Project. P. Place and pay for advertisement for Bids in appropriate publications. Q. Furnish to Engineer data as to Owner’s anticipated costs for services to be provided by others (including, but not limited to, accounting, bond and financial, independent cost estimating, insurance counseling, and legal advice) for Owner so that Engineer may assist Owner in collating the various cost categories which comprise Total Project Costs. R. Attend and participate in the pre-bid conference, bid opening, pre-construction conferences, construction progress and other job related meetings, and Site visits to determine Substantial Completion and readiness of the completed Work for final payment. S. Authorize Engineer to provide Additional Services as set forth in Part 2 of Exhibit A of the Agreement, as required. T. Perform or provide the following: [Sampling and testing deemed necessary to fill identified data gaps.] Exhibit C – Compensation Packet BC-6: Basic Services (other than RPR) – Salary Costs Times a Factor Method of Payment. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT C, consisting of [4] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Payments to Engineer for Services and Reimbursable Expenses COMPENSATION PACKET BC-1: Basic Services – Lump Sum Article 2 of the Agreement is supplemented to include the following agreement of the parties: ARTICLE 2 – OWNER’S RESPONSIBILITIES C2.01 Compensation for Basic Services (other than Resident Project Representative) – Lump Sum Method of Payment A. Owner shall pay Engineer for Basic Services set forth in Exhibit A, except for services of Engineer’s Resident Project Representative, if any, as follows: 1. A Lump Sum amount of $[159,960] based on the following estimated distribution of compensation: a. Study and Report Phase $[159,960] b. Preliminary Design Phase $[0] c. Final Design Phase $[0] d. Bidding and Negotiating Phase $[0] e. Construction Phase $[0] f. Post-Construction Phase $[0] 2. Engineer may alter the distribution of compensation between individual phases noted herein to be consistent with services actually rendered, but shall not exceed the total Lump Sum amount unless approved in writing by the Owner. 3. The Lump Sum includes compensation for Engineer’s services and services of Engineer’s Consultants, if any. Appropriate amounts have been incorporated in the Lump Sum to account for labor costs, overhead, profit, expenses (other than any expressly allowed Reimbursable Expenses), and Consultant charges. 4. In addition to the Lump Sum, Engineer is also entitled to reimbursement from Owner for the following Reimbursable Expenses: [None]. 5. The portion of the Lump Sum amount billed for Engineer’s services will be based upon Engineer’s estimate of the percentage of the total services actually completed during the billing period. If any Reimbursable Expenses are expressly allowed, Engineer may also bill for any such Reimbursable Expenses incurred during the billing period. Exhibit C – Compensation Packet BC-6: Basic Services (other than RPR) – Salary Costs Times a Factor Method of Payment. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 B. Period of Service: The compensation amount stipulated in Compensation Packet BC-1 is conditioned on a period of service not exceeding 11] months. If such period of service is extended, the compensation amount for Engineer's services shall be appropriately adjusted. Exhibit C – Compensation Packet AS-1: Additional Services – Standard Hourly Rates Method of Payment. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 COMPENSATION PACKET AS-1: Additional Services – Standard Hourly Rates Article 2 of the Agreement is supplemented to include the following agreement of the parties: C2.05 Compensation for Additional Services – Standard Hourly Rates Method of Payment A. Owner shall pay Engineer for Additional Services, if any, as follows: 1. General: For services of Engineer’s personnel engaged directly on the Project pursuant to Paragraph A2.01 or A2.02 of Exhibit A, except for services as a consultant or witness under Paragraph A2.01.A.20, (which if needed shall be separately negotiated based on the nature of the required consultation or testimony) an amount equal to the cumulative hours charged to the Project by each class of Engineer’s personnel times Standard Hourly Rates for each applicable billing class for all Additional Services performed on the Project, plus related Reimbursable Expenses and Engineer’s Consultant’s charges, if any. B. Compensation For Reimbursable Expenses: 1. For those Reimbursable Expenses that are not accounted for in the compensation for Basic Services under Paragraph C2.01 and are directly related to the provision of Additional Services, Owner shall pay Engineer at the rates set forth in Appendix 1 to this Exhibit C. 2. Reimbursable Expenses include the expenses identified in Appendix 1 and the following categories: transportation (including mileage), lodging, and subsistence incidental thereto; providing and maintaining field office facilities including furnishings and utilities; toll telephone calls, mobile phone charges, and courier charges; reproduction of reports, Drawings, Specifications, bidding-related or other procurement documents, Construction Contract Documents, and similar Project-related items; and Consultants’ charges. In addition, if authorized in advance by Owner, Reimbursable Expenses will also include expenses incurred for the use of highly specialized equipment. 3. The amounts payable to Engineer for Reimbursable Expenses, if any, will be the Additional Services-related internal expenses actually incurred or allocated by Engineer, plus all invoiced external Reimbursable Expenses allocable to such Additional Services, the latter multiplied by a factor of [1.10]. 4. The Reimbursable Expenses Schedule will be adjusted annually (as of [2021]) to reflect equitable changes in the compensation payable to Engineer. C. Other Provisions Concerning Payment for Additional Services: 1. Whenever Engineer is entitled to compensation for the charges of Engineer’s Consultants, those charges shall be the amounts billed by Engineer’s Consultants to Engineer times a factor of [1.15]. Exhibit C – Compensation Packet AS-1: Additional Services – Standard Hourly Rates Method of Payment. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 2. Factors: The external Reimbursable Expenses and Engineer’s Consultant’s Factors include Engineer’s overhead and profit associated with Engineer’s responsibility for the administration of such services and costs. 3. To the extent necessary to verify Engineer’s charges and upon Owner’s timely request, Engineer shall make copies of such records available to Owner at cost. Exhibit C – Appendix 1: Reimbursable Expenses Schedule. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is Appendix 1 to EXHIBIT C, consisting of [1] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Reimbursable Expenses Schedule Reimbursable Expenses are subject to review and adjustment per Exhibit C. Rates and charges for Reimbursable Expenses as of the date of the Agreement are: 8"x11" B&W Copies/Impressions $ [0.10]/page 8"x11" Color Copies/Impressions $ [1.00]/page 11"x17" B&W Copies/Impressions $ [0.25]/page 11"x17" Color Copies/Impressions $ [2.00]/page Copies of Drawings (22” x 34” plots on bond) $ [5.00]/page Mileage (auto) $ [0.60]/mile Air Transportation at cost plus 10% CAD Charge $ [110.00]/hour Laboratory Testing at cost plus 10% Nuclear Density Gauge $ [75.00]/day GPS Unit $ [250.00]/day Meals and Lodging at cost Exhibit C – Appendix 2: Standard Hourly Rates Schedule. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is Appendix 2 to EXHIBIT C, consisting of [2] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Standard Hourly Rates Schedule A. Standard Hourly Rates: 1. Standard Hourly Rates are set forth in this Appendix 2 to this Exhibit C and include salaries and wages paid to personnel in each billing class plus the cost of customary and statutory benefits, general and administrative overhead, non-project operating costs, and operating margin or profit. 2. The Standard Hourly Rates apply only as specified in Article C2. B. Schedule: TITLE CODE RATE SCHEDULE 01 REXBURG, IDAHO Work Classification Hourly Rate 1. Work Classification Hourly Rate Engineer/Scientist I Staff Engineer $90 Inspector III Senior Inspector 90 Engineer/Scientist II Project Engineer 110 Inspector IV Specialist Inspector 115 Engineer/Scientist III Project Manager/Engineer 130 Inspector V Supervising Inspector 130 Engineer/Scientist IV Project Manager 150 GIS/Planner I Assistant GIS Tech. 60 Engineer/Scientist V Division Manager 180 GIS/Planner II Project GIS Technician 75 Engineer/Scientist VI Principal Engineer 210 GIS/Planner III Senior GIS Technician 90 Engineering Technician. I Assistant Technician 60 GIS/Planner IV Specialist GIS Tech. 105 Engineering Technician. II Project Technician 75 GIS/Planner V Supervising GIS Tech 115 Engineering Technician III Senior Technician 90 Administrative I Receptionist 50 Engineering Technician IV Senior Technician 105 Administrative II Secretary 60 Engineering Technician V Supervising Technician 115 Administrative III Senior Secretary 75 Engineering Technician VI Supervising Technician 130 Administrative IV Office Manager 90 CAD Drafter I Drafter 60 Survey Technician I Rod Man 60 CAD Drafter II Senior Drafter 75 Survey Technician II Instrument Man 75 CAD Drafter III Designer 90 Survey Technician III Senior Surveyor 90 CAD Drafter IV Senior Designer 105 Surveyor IV Party Chief 105 Exhibit C – Appendix 2: Standard Hourly Rates Schedule. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 CAD Drafter V CAD Manager 115 Surveyor V Survey Manager 115 Inspector I Assisting Inspector 60 Surveyor V Chief of Survey 130 Inspector II Project Inspector 75 2-Man Survey Crew 190 • Hourly rates may change at the start of each calendar year or other times as negotiated with client. FA01-01/16 • Rates are fully-loaded with direct labor, overhead and profit • Expert Witness Testimony and Preparation will be charged at a rate of $500.00 per hour. • Reimbursable are charged at cost plus 15% • Subconsultants are charged at cost plus 15% • Related Project Fee (RPF) of $5.00 will be included per each direct labor hour to cover the costs of in-house reproduction services (including graphics, photocopying, and color printing), cell phone charges, long-distance calls, facsimiles, postage, overnight services, and CAD/computer and software usage. • Expense rates may change at the start of each calendar year or other times as negotiated with client. Exhibit H - Dispute Resolution. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT H, consisting of [1] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Dispute Resolution Paragraph 6.09 of the Agreement is supplemented to include the following agreement of the parties: H6.08 Dispute Resolution A. Mediation: Owner and Engineer agree that they shall first submit any and all unsettled claims, counterclaims, disputes, and other matters in question between them arising out of or relating to this Agreement or the breach thereof (“Disputes”) to mediation by [as agreed upon by Owner and Engineer]. Owner and Engineer agree to participate in the mediation process in good faith. The process shall be conducted on a confidential basis, and shall be completed within 120 days. If such mediation is unsuccessful in resolving a Dispute, then (1) the parties may mutually agree to a dispute resolution of their choice, or (2) either party may seek to have the Dispute resolved by a court of competent jurisdiction. Exhibit I - Limitations on Liability. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT I, consisting of [1] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. Limitations of Liability Paragraph 6.11 of the Agreement is supplemented to include the following agreement of the parties: A. Limitation of Engineer’s Liability 1. Engineer’s Liability Limited to Stated Amount, or Amount of Engineer’s Compensation: To the fullest extent permitted by Laws and Regulations, and notwithstanding any other provision of this Agreement, the total liability, in the aggregate, of Engineer and Engineer’s officers, directors, members, partners, agents, employees, and Consultants, to Owner and anyone claiming by, through, or under Owner for any and all injuries, claims, losses, expenses, costs, or damages whatsoever arising out of, resulting from, or in any way related to the Project, Engineer’s or its Consultants’ services. or this Agreement, from any cause or causes whatsoever, including but not limited to the negligence, professional errors or omissions, strict liability, breach of contract, indemnity obligations, or warranty express or implied, of Engineer or Engineer’s officers, directors, members, partners, agents, employees, or Consultants, shall not exceed the total amount of $[50,000] or the total compensation received by Engineer under this Agreement, whichever is greater. Higher limits are available for an additional fee. B. Indemnification by Owner: To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Engineer and its officers, directors, members, partners, agents, employees, and Consultants from and against any and all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court, arbitration, or other dispute resolution costs) arising out of or relating to the Project, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom, but only to the extent caused by any negligent act or omission of Owner or Owner’s officers, directors, members, partners, agents, employees, consultants, or others retained by or under contract to the Owner with respect to this Agreement or to the Project. Exhibit K – Amendment to Owner-Engineer Agreement. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 1 This is EXHIBIT K, consisting of [2] pages, referred to in and part of the Agreement between Owner and Engineer for Professional Services dated [December 4, 2019]. AMENDMENT TO OWNER-ENGINEER AGREEMENT Amendment No. _____ The Effective Date of this Amendment is: ______. Background Data Effective Date of Owner-Engineer Agreement: Owner: Engineer: Project: Nature of Amendment: [Check those that are applicable and delete those that are inapplicable.] ____ Additional Services to be performed by Engineer ____ Modifications to services of Engineer ____ Modifications to responsibilities of Owner ____ Modifications of payment to Engineer ____ Modifications to time(s) for rendering services ____ Modifications to other terms and conditions of the Agreement Description of Modifications: Here describe the modifications, in as much specificity and detail as needed. Use an attachment if necessary. Agreement Summary: Original agreement amount: $_____________ Net change for prior amendments: $_____________ This amendment amount: $_____________ Adjusted Agreement amount: $_____________ Change in time for services (days or date, as applicable): ______ Exhibit K – Amendment to Owner-Engineer Agreement. EJCDC® E-500, Agreement Between Owner and Engineer for Professional Services. Copyright © 2014 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 2 The foregoing Agreement Summary is for reference only and does not alter the terms of the Agreement, including those set forth in Exhibit C. Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. All provisions of the Agreement not modified by this or previous Amendments remain in effect. OWNER: ENGINEER: By: By: Print name: Print name: Title: Title: Date Signed: Date Signed: